The Green Hill Solar Farm Order 2026

SCHEDULE 15 PROTECTIVE PROVISIONS

Article 45 PART 1 FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS 1 For the protection of the utility undertakers referred to in this Part of this Schedule (save for any utility undertakers which are specifically protected by any other Part of this Schedule, which will take precedence), the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertakers concerned. 2 In this Part of this Schedule— “alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner not less efficient than previously; “apparatus” means— in the case of an electricity undertaker, electric lines or electrical plant (as defined in the 1989 Act, belonging to or maintained by that utility undertaker; in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter for the purposes of gas supply; in the case of a water undertaker— mains, pipes or other apparatus belonging to or maintained by that utility undertaker for the purposes of water supply; and any water mains or service pipes (or part of a water main or service pipe) that is the subject of an agreement to adopt made under section 51A of the Water Industry Act 1991; in the case of a sewerage undertaker— any drain or works vested in the utility undertaker under the Water Industry Act 1991; and any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act, and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus; and any other mains, pipelines or cables that are not the subject of the protective provisions in Parts 2 to 9 of this Schedule; “functions” includes powers and duties; “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and “utility undertaker” means— any licence holder within the meaning of Part 1 of the 1989 Act; a gas transporter within the meaning of Part 1 of the Gas Act 1986; water undertaker within the meaning of the Water Industry Act 1991; a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991; and an owner or operator of apparatus within paragraph (e) of the definition of that term, for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained. 3 This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 of the 1991 Act. 4 Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 12 (temporary closure, restriction or prohibition of use of streets and public rights of way), a utility undertaker is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street. 5 Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement. 6 (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (7). (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus. (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed. (4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 44 (arbitration). (5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 44, and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule. (6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that it desires itself to execute any work, or part of any work, in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker. (7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus. 7 (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 44 (arbitration). (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. 8 (1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 6(2), the undertaker must submit to the utility undertaker in question a plan, section and description of the works to be executed. (2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works. (3) Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it. (4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 7 apply as if the removal of the apparatus had been required by the undertaker under paragraph 6(2). (5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description. (6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case, it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances. 9 (1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker the reasonable expenses incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 6(2). (2) There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule, that value being calculated after removal. (3) If in accordance with the provisions of this Part of this Schedule— (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 44 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) is to be reduced by the amount of that excess. (4) For the purposes of sub-paragraph (3)— (a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 6(2); and (b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined. (5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit. 10 (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 6(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must— (a) bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and (b) make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker, by reason or in consequence of any such damage or interruption. (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents. (3) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand. 11 Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaking in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made. PART 2 FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS 12 For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator. 13 In this Part of this Schedule— “the 2003 Act” means the Communications Act 2003; “electronic communications apparatus” has the same meaning as in the electronic communications code; “electronic communications code” has the same meaning as in section 106 (application of the electronic communications code) of the 2003 Act; “electronic communications code network” means— so much of an electronic communications network or conduit system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; and an electronic communications network which the Secretary of State is providing or proposing to provide; “electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act; and “operator” means the operator of an electronic communications code network. 14 The exercise of the powers of article 33 (statutory undertakers) is subject to Part 10 (undertakers’ works affecting electronic communications apparatus) of the electronic communications code. 15 (1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works— (a) any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or (b) there is any interruption in the supply of the service provided by an operator, the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption. (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents. (3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand. (4) Any difference arising between the undertaker and the operator under this Part of this Schedule must be referred to and settled by arbitration under article 44 (arbitration). 16 This Part of this Schedule does not apply to— (a) any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act; or (b) any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised development. 17 Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made. PART 3 FOR THE PROTECTION OF NATIONAL GRID ELECTRICITY TRANSMISSION PLC Application 18 (1) For the protection of National Grid as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing, between the undertaker and National Grid. (2) Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the undertaker and National Grid, where the benefit of this Order is transferred or granted to another person under article 37 (consent to transfer the benefit of the Order)— (a) any agreement of the type mentioned in sub-paragraph (1) has effect as if it had been made between National Grid and the transferee or grantee (as the case may be); and (b) written notice of the transfer or grant must be given to National Grid on or before the date of that transfer or grant. (3) Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to National Grid (but without prejudice to paragraph 33(3)(b)). Interpretation 19 In this Part of this Schedule— “acceptable credit provider” means a bank or financial institution with a credit rating that is not lower than: (i) “A-” if the rating is assigned by Standard & Poor’s Ratings Group or Fitch Ratings; and “A3” if the rating is assigned by Moody’s Investors Services Inc.; “acceptable insurance” means general third party liability insurance effected and maintained by the undertaker with a combined property damage and bodily injury limit of indemnity of not less than £50,000,000.00 (fifty million pounds) per occurrence or series of occurrences arising out of one event. Such insurance shall be maintained (a) during the construction period of the authorised works; and (b) after the construction period of the authorised works in respect of any use and maintenance works of the authorised works by or on behalf of the undertaker which constitute specified works and arranged with an insurer whose security/credit rating meets the same requirements as an “acceptable credit provider”, such insurance shall include (without limitation)— a waiver of subrogation and an indemnity to principal clause in favour of National Grid; pollution liability for third party property damage and third party bodily damage arising from any pollution/contamination event with a (sub)limit of indemnity of not less than £10,000,000.00 (ten million pounds) per occurrence or series of occurrences arising out of one event or £20,000,000.00 (twenty million pounds) in aggregate; “acceptable security” means either— a parent company guarantee from a parent company in favour of National Grid to cover the undertaker’s liability to National Grid to a total liability cap of £50,000,000.00 (fifty million pounds) (in a form reasonably satisfactory to National Grid and where required by National Grid, accompanied with a legal opinion confirming the due capacity and authorisation of the parent company to enter into and be bound by the terms of such guarantee); or a bank bond or letter of credit from an acceptable credit provider in favour of National Grid to cover the undertaker’s liability to National Grid for an amount of not less than £10,000,000.00 (ten million pounds) per asset per event up to a total liability cap of £50,000,000.00 (fifty million pounds) (in a form reasonably satisfactory to National Grid); “alternative apparatus” means appropriate alternative apparatus to the satisfaction of National Grid to enable National Grid to fulfil its statutory functions in a manner no less efficient than previously; “apparatus” means— electric lines or electrical plant as defined in the 1989 Act, belonging to or maintained by National Grid together with any replacement apparatus; such other apparatus constructed pursuant to the Order that becomes operational apparatus of National Grid for the purposes of transmission, distribution and/or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus; any electrical lines or electrical plant as defined in the 1989 Act, any mains, pipes, plant or other apparatus belonging to, operated or maintained by National Grid for the purposes of the construction, operation and maintenance of the WMEL Project and/or, whether temporary or permanent, and includes, where the context so requires, apparatus constructed as part of the authorised works and intended for the beneficial use by National Grid (“WMEL Project apparatus”); and any electrical lines or electrical plant as defined in the 1989 Act, any mains, pipes, plant or other apparatus belonging to, operated or maintained by National Grid for the purposes of the construction, operation and maintenance of the SGRE Project and/or, whether temporary or permanent, and includes, where the context so requires, apparatus constructed as part of the authorised works and intended for the beneficial use by National Grid (“SGRE Project apparatus”); “authorised works” has the same meaning as is given to the term “authorised development” in article 2 (interpretation) of this Order and includes any associated development authorised by the Order and for the purposes of this Part of this Schedule includes the use and maintenance of the authorised works and construction of any works authorised by this Part of this Schedule; “commence” and “commencement” in this Part of this Schedule shall include any below ground surveys, monitoring, ground work operations or the receipt and erection of construction plant and equipment; “deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, enactments and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule; “functions” includes powers and duties; “ground mitigation scheme” means a scheme approved by National Grid (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event; “ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, shall require the undertaker to submit for National Grid’s approval a ground mitigation scheme; “ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme; “in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land; “incentive deduction” means any incentive deduction National Grid receives under its electricity transmission licence which is caused by an event on its transmission system that causes electricity not to be supplied to a demand customer and which arises as a result of the authorised works; “maintain” and “maintenance” shall include the ability and right to do any of the following in relation to any apparatus or alternative apparatus of National Grid, to construct, use, repair, alter, inspect, renew or remove the apparatus; “NESO” means as is defined in the STC; “parent company” means a parent company of the undertaker acceptable to and which shall have been approved by National Grid acting reasonably; “plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary to properly and sufficiently describe and assess the works to be executed; “SGRE Project” means reinforcement and upgrade of the conductor on the existing 400kV double circuit overhead line from Grendon to Sundon and associated works to be undertaken by National Grid and any temporary construction compounds and laydown areas for such works; “SGRE Site” includes— land on which any SGRE apparatus is situated; and land on which SGRE apparatus is anticipated to be situated which is necessary for the construction, use or maintenance of the SGRE Project (in so far as the same has been notified by National Grid in writing to the undertaker); “shared area” means any area that is both within the Order limits and at least one of the WMEL Project site and the SGRE Project site; “shared area works” means so much of the authorised works to be carried out within the shared area; “specified works” means any of the authorised works or activities undertaken in association with the authorised works which— will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph 29 or otherwise; or may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under paragraph 29 or otherwise; or includes any of the activities that are referred to in development near overhead lines EN43-8 and HSE’s guidance note 6 “Avoidance of Danger from Overhead Lines”; “STC” means the System Operator Transmission Owner Code prepared by the electricity transmission owners and NESO as modified from time to time; “STC claims” means any claim made under the STC against National Grid arising out of or in connection with the de-energisation (whereby no electricity can flow to or from the relevant system through the generator or interconnector’s equipment) of a generator or interconnector party solely as a result of the de-energisation of plant and apparatus forming part of National Grid’s transmission system which arises as a result of the authorised works; “transmission owner” is as defined in the STC; “WMEL Project” means the proposed Weston Marsh to East Leicestershire Project being the construction of two new substations near Corby Glen and Wartnaby in Leicestershire and new overhead line between the new substations and the Weston Marsh substation and associated works to be undertaken by and any temporary construction compounds and laydown areas for such works; and “WMEL Site” includes— land on which any WMEL apparatus is situated; and land on which WMEL apparatus is anticipated to be situated which is necessary for the construction, use or maintenance of the WMEL Project (in so far as the same has been notified by National Grid in writing to the undertaker). Interaction with the SGRE Project and/or the WMEL Project 20 Without limiting any other provision of this Part of this Schedule, the undertaker must use reasonable endeavours to avoid any conflict arising between the construction, maintenance and operation of the authorised works and the SGRE Project and/or the WMEL Project. For the purposes of this paragraph, “reasonable endeavours” means— (a) undertaking consultation on the detailed design and programming of the shared area works and all works associated with or ancillary to the shared area works to ensure that the design and programme for the Green Hill project works does not unreasonably impede or interfere with the SGRE Project and/or the WMEL Project; (b) having regard to the proposed programme of works for the SGRE Project and/or the WMEL Project as may be made available to the undertaker by National Grid Electricity Transmission Plc and facilitating a co-ordinated approach to the programme, land assembly, and the carrying out of the shared area works and the SGRE Project and/or the WMEL Project; (c) providing a point of contact for continuing liaison and co-ordination throughout the construction and operation of the authorised works; and (d) keeping National Grid Electricity Transmission Plc informed on the programme of works for the authorised works. Shared area works 21 The undertaker must not except with the prior written agreement of National Grid carry out the shared area works, or any part of it. 22 (1) Before beginning to construct any shared area works, or any part of it, the undertaker must submit to National Grid plans of the relevant shared area works (or part of it) and such further particulars available to it as National Grid Plc may request within 21 days of receipt of the plans reasonably requested. (2) Any shared area works must not be constructed except in accordance with such plans as may be approved in writing by National Grid. 23 (1) Any approval of National Grid required under this Schedule— (a) must not be unreasonably withheld or delayed; (b) in the case of a refusal must be accompanied by a statement of grounds or refusal; and (c) may be given subject to such reasonable requirements as National Grid may have in connection with the safe, economic and efficient construction, commissioning, operation, maintenance and future decommissioning of the SGRE Project and/or the WMEL Project or otherwise for the protection of the SGRE Project apparatus and/or the WMEL Project apparatus, provided always that in relation to a refusal under sub-paragraph (b) or any requirements requested pursuant to sub-paragraph (c) the undertaker shall be permitted to refer such matters to dispute resolution pursuant to paragraph 37. (2) National Grid must employ reasonable endeavours to respond to the submission of any plans within a period of 56 days from the date of submission of the plans. If National Grid require further particulars, such particulars must be requested by National Grid no later than 21 days from the submission of plans and thereafter National Grid Electricity Transmission Plc must employ reasonable endeavours to respond to the submission within 56 days from receipt of the further particulars. 24 (1) The undertaker must give to National Grid not less than 14 days’ notice in writing of its intention to commence construction of any shared area works and notice in writing of its completion not later than 7 days after the date on which it is completed and National Grid Electricity Transmission Plc will be entitled by its officer to watch and inspect the construction of such works. (2) If any part of the shared area works is constructed otherwise than in accordance with paragraph 22(2) above National Grid Electricity Transmission Plc may by notice in writing identify the extent to which the shared area works do not comply with the approved details and request the undertaker at the undertaker’s own expense carry out remedial works so as to comply with the requirements of paragraph 22(2) of this Schedule or such alternative works as may be agreed with National Grid Electricity Transmission Plc or as otherwise may be agreed between the parties. (3) Subject to sub-paragraph (4), if within a reasonable period, being not less than 28 days beginning with the date when a notice under sub-paragraph (2) is served upon the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, National Grid Electricity Transmission Plc may execute the works specified in the notice and any reasonable expenditure incurred by National Grid Electricity Transmission Plc in so doing will be recoverable from the undertaker. (4) In the event of any dispute as to whether sub-paragraph (2) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, National Grid Electricity Transmission Plc will not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (3) until the dispute has been finally determined in accordance with paragraph 37. On street apparatus 25 Except for paragraph 26 (apparatus of National Grid in streets subject to temporary prohibition or restriction of use), paragraph 31 (retained apparatus: protection of National Grid as electricity undertaker), paragraph 32 (expenses), and paragraph 33 (indemnity) of this Schedule which will apply in respect of the exercise of all or any powers under the Order affecting the rights and apparatus of National Grid, the provisions of this Part of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and National Grid are regulated by the provisions of Part 3 of the 1991 Act. Apparatus of National Grid in streets subject to temporary prohibition or restriction of use and public rights of way 26 Notwithstanding the temporary prohibition or restriction of use or diversion of a street or public right of way under the powers of article 12 (temporary closure, restriction or prohibition of use of streets and public rights of way), National Grid is at liberty at all times to take all necessary access across any such street or public right of way and to execute and do all such works and things in, upon or under any such street or public right of way as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction of use or diversion was in that street or public right of way. Protective works to buildings 27 The undertaker, in the case of the powers conferred by article 19 (protective works to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus, the SGRE Site or to the WMEL Site without the prior written consent of National Grid. Acquisition of land 28 (1) Regardless of any provision in this Order or anything shown on the land plan or contained in the book of reference to the Order, the undertaker may not appropriate or acquire or take temporary possession of any land or apparatus or appropriate, acquire, extinguish, interfere with or override any easement, other interest or right or apparatus of National Grid otherwise than by agreement. (2) Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not unless otherwise agreed in writing with National Grid appropriate, acquire or take temporary possession of any land forming part of the SGRE Site, the WMEL Site and/or any access thereto. (3) As a condition of an agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised works (or in such other timeframe as may be agreed between National Grid and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of National Grid or affect the provisions of any enactment or agreement regulating the relations between National Grid and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as National Grid reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between National Grid and the undertaker acting reasonably and which must be no less favourable on the whole to National Grid unless otherwise agreed by National Grid, and the undertaker must use reasonable endeavours to procure and/or secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works. (4) Save where otherwise agreed in writing between National Grid and the undertaker, the undertaker and National Grid agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation or removal of apparatus (including but not limited to the payment of costs and expenses relating to such relocation or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by National Grid or other enactments relied upon by National Grid as of right or other use in relation to the apparatus, then the provisions in this Part of this Schedule will prevail. (5) Any agreement or consent granted by National Grid under paragraph 31 or any other paragraph of this Part of this Schedule, will not be taken to constitute agreement under sub-paragraph 28(1). Removal of apparatus 29 (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in or possesses temporarily any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of National Grid to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of National Grid in accordance with sub-paragraphs (2) to (5). (2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to National Grid advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order National Grid reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), secure any necessary consents for the alternative apparatus and afford to National Grid to its satisfaction (taking into account paragraph 30(1) ) the necessary facilities and rights— (a) for the construction of alternative apparatus in other land of or land secured by the undertaker; and (b) subsequently for the maintenance of that apparatus. (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, National Grid may in its sole discretion, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances to assist the undertaker to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation does not extend to the requirement for National Grid to use its compulsory purchase powers to this end unless it elects to so do. (4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between National Grid and the undertaker. (5) National Grid must, after the alternative apparatus to be provided or constructed has been agreed, and subject to a written diversion agreement having been entered into between the parties and the grant to National Grid of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule. Facilities and rights for alternative apparatus 30 (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for National Grid facilities and rights in land for the construction, use, maintenance and protection of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and National Grid and must be no less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by National Grid. (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the matter may be referred to arbitration in accordance with paragraph 37 (arbitration) of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to National Grid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. Retained apparatus: protection of National Grid as electricity undertaker 31 (1) Not less than 56 days before the commencement of any specified works, the undertaker must submit to National Grid a plan of the works to be executed and seek from National Grid details of the underground extent of their electricity assets. (2) In relation to specified works, the plan to be submitted to National Grid under sub-paragraph (1) must include a method statement and describe— (a) the exact position of the works; (b) the level at which these are proposed to be constructed or renewed; (c) the manner of their construction or renewal including details of excavation, positioning of plant; (d) the position of all apparatus; (e) by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus; (f) any intended maintenance regimes; (g) an assessment of risks of rise of earth issues; and (h) a ground monitoring scheme, where required. (3) In relation to any works which will or may be situated on, over, under or within 10 metres of any part of the foundations of an electricity tower or between any two or more electricity towers, the plan to be submitted under sub-paragraph (1) must, in addition to the matters set out in sub-paragraph (2), include a method statement describing— (a) details of any cable trench design including route, dimensions, clearance to pylon foundations; (b) demonstration that pylon foundations will not be affected prior to, during and post construction; (c) details of load bearing capacities of trenches; (d) details of any cable installation methodology including access arrangements, jointing bays and backfill methodology; (e) a written management plan for high voltage hazard during construction and ongoing maintenance of any cable route; (f) written details of the operations and maintenance regime for any cable, including frequency and method of access; (g) assessment of earth rise potential if reasonably required by National Grid’s engineers; and (h) evidence that trench bearing capacity is to be designed to support overhead line construction traffic of up to and including 26 tonnes in weight. (4) The undertaker must not commence any works to which sub-paragraphs (2) or (3) apply until National Grid has given written approval of the plan so submitted. (5) Any approval of National Grid required under sub-paragraph (4)— (a) may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs (6) or (8); (b) may be given subject to such reasonable requirements as National Grid may have in connection with the safe and efficient construction, commissioning, operation and maintenance of the SGRE Project and/or the WMEL Project; and (c) must not be unreasonably withheld. (6) In relation to any works to which sub-paragraph (2) or (1)apply, National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage or for the provision of protective works or for the purpose of providing or securing proper and convenient means of access to any apparatus. (7) Works executed under sub-paragraphs (2) or (3) must be executed in accordance with the plan submitted under sub-paragraph (1), or as relevant sub-paragraph (6), as approved or as amended from time to time by agreement between the undertaker and National Grid and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (6) or (8) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid will be entitled to watch and inspect the execution of those works. (8) Where National Grid requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, such protective works must be carried out to National Grid’s satisfaction prior to the commencement of any authorised works (or any relevant part thereof) for which protective works are required and National Grid shall give notice of its requirement for such works within 42 days of the date of submission of a plan pursuant to this paragraph (except in an emergency). (9) If National Grid in accordance with sub-paragraphs (6) or (8) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 18-20 and sub-paragraphs (6) to (8) apply as if the removal of the apparatus had been required by the undertaker under paragraph 29(2). (10) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the authorised works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph shall apply to and in respect of the new plan. (11) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in section 52 of the 1991 Act but in that case, it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and must comply with— (a) sub-paragraphs (6), (7) and (8) insofar as is reasonably practicable in the circumstances; and (b) sub-paragraph (12) at all times. (12) At all times when carrying out any works authorised under this Order, the undertaker must comply with National Grid’s policies for development near overhead lines EN43-8 and the Health and Safety Executive’s guidance note 6 “Avoidance of Danger from Overhead Lines”. Expenses 32 (1) Save where otherwise agreed in writing between National Grid and the undertaker and subject to the following provisions of this paragraph, the undertaker must pay to National Grid within 30 days of receipt of an itemised invoice or claim from National Grid all charges, costs and expenses reasonably anticipated within the following three months or reasonably or properly incurred by National Grid in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised works as are referred to in this Part of this Schedule including without limitation— (a) any costs reasonably incurred by or compensation properly paid by National Grid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs incurred by National Grid as a consequence of National Grid— (i) using its own compulsory purchase powers to acquire any necessary rights under paragraph 29(3); or (ii) exercising any compulsory purchase powers in the Order transferred to or benefitting National Grid; (b) in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus, where no written diversion agreement is otherwise in place; (c) the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus; (d) the approval of plans; (e) the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works; and (f) the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule. (2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal. (3) If in accordance with the provisions of this Part of this Schedule— (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 37 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Grid by virtue of sub-paragraph (1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker. (4) For the purposes of sub-paragraph (3)— (a) an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and (b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined. (5) Any amount which apart from this sub-paragraph would be payable to National Grid in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Grid any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit. Indemnity 33 (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Part of this Schedule or in consequence of the construction, use, maintenance or failure of any of the specified works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the specified works) or property of National Grid, or there is any interruption in any service provided, or in the supply of any goods, by National Grid, or National Grid becomes liable to pay any amount to any third party, the undertaker will— (a) bear and pay on demand accompanied by an invoice or claim from National Grid the cost reasonably and properly incurred by National Grid in making good such damage or restoring the supply; and (b) indemnify National Grid for any other expenses, loss, demands, proceedings, damages, claims, penalties or costs incurred by or recovered from National Grid, by reason or in consequence of any such damage or interruption or National Grid becoming liable to any third party and including STC claims or an incentive deduction other than arising from any default of National Grid. (2) The fact that any act or thing may have been done by National Grid on behalf of the undertaker or in accordance with a plan approved by National Grid or in accordance with any requirement of National Grid or under its supervision will not (unless sub-paragraph (3) applies), excuse the undertaker from liability under the provisions of this sub-paragraph unless National Grid fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan. (3) Nothing in sub-paragraph (1) imposes any liability on the undertaker in respect of— (a) any damage or interruption to the extent that it is attributable to the neglect or default of National Grid, its officers, servants, contractors or agents; (b) any indirect or consequential loss of any third party (including but not limited to loss of use, revenue, profit, contract, production, increased cost of working or business interruption) arising from any such damage or interruption, which is not reasonably foreseeable; or (c) any specified works or any other works authorised by this Part of this Schedule carried out by National Grid as an assignee, transferee or lessee of the undertaker with the benefit of the Order pursuant to section 156 of the 2008 Act or article 37 (consent to transfer the benefit of the Order) subject to the proviso that once such works become apparatus (“new apparatus”), any authorised works yet to be executed and not falling within this paragraph 33(3)(b) will be subject to the full terms of this Part of this Schedule including this paragraph 33; or (4) National Grid must give the undertaker reasonable written notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting with the undertaker and considering their representations. (5) National Grid must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds. (6) National Grid must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within National Grid’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of National Grid’s control and if reasonably requested to do so by the undertaker National Grid must provide an explanation of how the claim has been minimised, where relevant. (7) Not to commence construction (and not to permit the commencement of such construction) of the authorised works on any land owned by National Grid or in respect of which National Grid has an easement or wayleave for its apparatus or any other interest or to carry out any works within 15 metres of National Grid’s apparatus until the following conditions are satisfied— (a) unless and until National Grid is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has first provided the acceptable security and provided evidence that it shall maintain such acceptable security for the construction period of the authorised works from the proposed date of commencement of construction of the authorised works and National Grid has confirmed the same to the undertaker in writing; and (b) unless and until National Grid is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has procured acceptable insurance and provided evidence to National Grid that it shall maintain such acceptable insurance for the construction period of the authorised works from the proposed date of commencement of construction of the authorised works and National Grid has confirmed the same in writing to the undertaker. (8) In the event that the undertaker fails to comply with sub-paragraph (7), nothing in this Part of this Schedule will prevent National Grid from seeking injunctive relief (or any other equitable remedy) in any court of competent jurisdiction. Enactments and agreements 34 Save to the extent provided for to the contrary elsewhere in this Part of this Schedule or by agreement in writing between National Grid and the undertaker, nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and National Grid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made. Co-operation 35 (1) Where in consequence of the proposed construction of any part of the authorised works, the undertaker or National Grid requires the removal of apparatus under paragraph 29(2) or National Grid makes requirements for the protection or alteration of apparatus under paragraph 31, the undertaker will use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised works and taking into account the need to ensure the safe and efficient operation of National Grid’s undertaking and National Grid will use its best endeavours to co-operate with the undertaker for that purpose. (2) Whenever National Grid’s consent, agreement or approval is required in relation to plans, documents or other information submitted by the undertaker or the taking of action by the undertaker, it must not be unreasonably withheld or delayed. Access 36 If in consequence of the agreement reached in accordance with paragraph 28 or the powers granted under this Order the access to any apparatus, the SGRE Site and/or the WMEL Site is materially obstructed, the undertaker must provide such alternative means of access to such apparatus, the SGRE Site and/or the WMEL Site as will enable National Grid to access, maintain or use the apparatus, the SGRE Site and/or the WMEL Site no less effectively than was possible before such obstruction. Arbitration 37 Save for differences or disputes arising under paragraphs 29(2), 29(4), 30(1) and 31, any difference or dispute arising between the undertaker and National Grid under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and National Grid, be determined by arbitration in accordance with article 44 (arbitration). Notices 38 Any plans submitted to National Grid by the undertaker pursuant to this Part of this Schedule must be submitted using the LSBUD system (https://lsbud.co.uk) or to such other address as National Grid may from time to time appoint instead for that purpose and notify to the undertaker in writing. PART 4 FOR THE PROTECTION OF NATIONAL GRID ELECTRICITY DISTRIBUTION (EAST MIDLANDS) PLC AS ELECTRICITY UNDERTAKER Application 39 For the protection of National Grid Electricity Distribution (East Midlands) plc the following provisions, unless otherwise agreed in writing between the undertaker and National Grid Electricity Distribution (East Midlands) plc, have effect. Interpretation 40 In this Part of this Schedule— “alternative apparatus” means alternative apparatus adequate to enable NGED to fulfil its statutory functions in a manner not less efficient than previously and where the context requires includes any part of such alternative apparatus; “alternative rights” means all and any necessary legal easements, leases, consents, or permissions required by NGED in order to permit or authorise a diversion and to permit or authorise NGED to lay, keep, operate, maintain, adjust, repair, alter, relay, renew, supplement, inspect, examine, test and remove the alternative apparatus; “apparatus” means electric lines or electrical plant as defined in the 1989 Act, belonging to or maintained by NGED; “diversion” means an alteration to the NGED Network in order to enable or facilitate the authorised development; “functions” includes powers and duties; “in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or upon land; “NGED” means National Grid Electricity Distribution (East Midlands) plc (company number 02366923) whose registered office is at Avonbank, Feeder Road, Bristol, BS2 0TB; “NGED Network” means NGED’s distribution network operated pursuant to its distribution licence issued pursuant to section 6 of the 1989 Act; “plan” or “plans” includes all designs, drawings, specifications, method statements, programmes, calculations, risk assessments and other documents that are reasonably necessary to properly and sufficiently describe and assess the works to be executed; and “specified work” means so much of any of the authorised development that is carried out within 6 metres of any apparatus. Precedence of 1991 Act in respect of apparatus in streets 41 This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and NGED are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act. 42 Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 12 (temporary closure, restriction or prohibition of use of streets and public rights of way), NGED is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street. No acquisition except by agreement 43 Regardless of any provision in this Order, the undertaker must not acquire any apparatus otherwise than by agreement. Removal of apparatus 44 (1) If, in the exercise of the powers conferred by this Order, the undertaker requires that apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule and any right of NGED to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, alternative rights acquired or granted for the alternative apparatus and the alternative apparatus is in operation and access to it has been provided if necessary to the reasonable satisfaction of NGED in accordance with sub-paragraphs (2) to (10) or with such alternative or supplementary provisions as the undertaker and NGED may agree between them. (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to NGED written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed. (3) If as a direct consequence of the exercise of any of the powers conferred by this Order NGED reasonably needs to remove or divert any of its apparatus and the removal of that apparatus has not been required by the undertaker under sub-paragraph (2) then NGED must give to the undertaker written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and this Part has effect as if the removal or diversion of such apparatus had been required by the undertaker under sub-paragraph (2). (4) If as a direct consequence of the removal or diversion of apparatus under sub-paragraph (2) or (3) alternative apparatus is to be constructed in land owned or controlled by the undertaker then the undertaker must afford to NGED the necessary facilities, alternative rights and any necessary third party consent or approvals for the construction of alternative apparatus in the other land owned or controlled by the undertaker. (5) If the undertaker or NGED requires to remove or divert any apparatus placed within the Order land and alternative apparatus is to be constructed in land not owned or controlled by the undertaker as a consequence of the removal or diversion of apparatus then NGED shall use its reasonable endeavours to obtain alternative rights in the land in which the alternative apparatus is to be constructed. (6) If alternative apparatus is to be constructed in land not owned or controlled by the undertaker and NGED is unable to obtain such alternative rights as are mentioned in sub-paragraph (5), the undertaker and NGED shall consider whether there is an alternative engineering solution that can achieve the diversion without the need for the use of compulsory powers. Should such an alternative engineering solution not be practicable and deliverable in a reasonable timescale and at a reasonable cost (which shall be determined by the undertaker acting reasonably), NGED may but shall not be compelled to use the powers of compulsory acquisition set out in this Order or the 1989 Act to obtain the necessary facilities and rights in the land outside the Order limits in which the alternative apparatus is to be constructed in accordance with a timetable agreed between NGED and the undertaker. (7) Any alternative apparatus required pursuant to sub-paragraphs (2) or (3) must be constructed in such manner and in such line or situation as may be agreed between NGED and the undertaker or in default of agreement settled in accordance with paragraph 49 (expert determination). (8) NGED must, after the alternative apparatus to be provided or constructed has been agreed or settled in accordance with paragraph 49(2) (expert determination) and, after the acquisition by or grant to NGED of any such facilities and alternative rights as are referred to in sub-paragraphs (2) to (6), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule. (9) Regardless of anything in sub-paragraph (8), if the undertaker gives notice in writing to NGED that it desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by NGED, must be executed by the undertaker— (a) in accordance with plans and specifications and in such line or situation agreed between the undertaker and NGED, or, in default of agreement, determined in accordance with paragraph 49(2) (expert determination); and (b) without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of NGED. (10) Nothing in sub-paragraph (9) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus or alternative apparatus, or execute any filling around the apparatus or alternative apparatus (where the apparatus or alternative apparatus is laid in a trench) within 600 millimetres of the point of connection or disconnection. Facilities and rights for alternative apparatus 45 (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to NGED facilities and alternative rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and alternative rights must be granted upon such terms and conditions as may be agreed between the undertaker and NGED or in default of agreement settled in accordance with paragraph 49(2) (expert determination). (2) In settling those terms and conditions in respect of alternative apparatus to be constructed in the land of the undertaker, the expert must— (a) give effect to all reasonable requirements of the undertaker for ensuring the safety and efficient operation of the authorised development and for securing any subsequent alterations or adaptations of the alternative apparatus which may be required to prevent interference with any proposed works of the undertaker; (b) have regard to the terms and conditions, if any, applicable to the apparatus for which the alternative apparatus is to be substituted; (c) have regard to NGED’s ability to fulfil its service obligations and comply with its licence conditions; and (d) have regard to the standard form rights NGED ordinarily secures for the type of alternative apparatus to be constructed in the circumstances similar to the authorised development. (3) If the facilities and alternative rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and alternative rights are to be granted, are in the opinion of the expert less favourable on the whole to NGED than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the expert must make such provision for the payment of compensation by the undertaker to NGED as appears to the expert to be reasonable having regard to all the circumstances of the particular case. Retained apparatus 46 (1) Not less than 60 days before the undertaker intends to start the execution of any specified work where the removal of the apparatus in question has not been required under paragraph 44 (removal of apparatus), the undertaker shall submit to NGED a plan of the works to be executed. Any submission must note the time limits imposed on NGED under sub-paragraph (3). (2) Subject to sub-paragraph (3) below the undertaker shall not commence any works to which sub-paragraph (1) applies until NGED has identified any reasonable requirements it has for the alteration or protection of the apparatus, or for securing access to it. (3) If by the expiry of 60 days beginning with the date on which a plan under sub-paragraph (1) is submitted NGED has not advised the undertaker in writing of any reasonable requirements for the alteration or protection of the apparatus, or for securing access to it, it shall be deemed not to have any such requirements and the undertaker shall be at liberty to proceed with the works. (4) The works referred to in sub-paragraph (1) must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with any reasonable requirements as may be notified in accordance with sub-paragraph (2) by NGED and NGED shall be entitled to watch and inspect the execution of those works. (5) At all times when carrying out the authorised development the undertaker must comply with NGED’s Avoidance of Danger from Electricity Overhead Lines and Underground Cables (2014), the Energy Network Association’s A Guide to the Safe Use of Mechanical Plant in the Vicinity of Electricity Overhead Lines (undated), the Health and Safety Executive’s GS6 Avoiding Danger from Overhead Power Lines, and the Health and Safety Executive’s HSG47 Avoiding Danger from Underground Services (Third Edition) (2014) as the same may be replaced from time to time. (6) If NGED, in accordance with sub-paragraph (2) and in consequence of the works proposed by the undertaker, reasonably requires the removal or diversion of any apparatus and gives written notice to the undertaker of that requirement, this Part of this Schedule applies as if the removal or diversion of the apparatus had been required by the undertaker under paragraph 44(3) (removal of apparatus). (7) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 60 days before commencing the execution of any works, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan. (8) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to NGED notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with any reasonable requirements stipulated by NGED under sub-paragraph (2) and with sub-paragraphs (4) and (5) in so far as is reasonably practicable in the circumstances. Nothing in this sub-paragraph prevents NGED from exercising its rights under sub-paragraph (6). Expenses and costs 47 (1) Subject to the following provisions of this paragraph, the undertaker must pay to NGED the proper and reasonable expenses reasonably incurred by NGED in, or in connection with, the inspection, removal, diversion, alteration or protection of any apparatus, the construction of any alternative apparatus and the acquisition or grant of alternative rights for the alternative apparatus, arising as a result of the powers conferred upon the undertaker pursuant to this Order. (2) The value of any apparatus removed under the provisions of this Part of this Schedule must be deducted from any sum payable under sub-paragraph (1), that value being calculated after removal. (3) If in accordance with the provisions of this Part of this Schedule NGED requires that alternative apparatus of better type, of greater capacity, of greater dimensions or at a greater depth is necessary in substitution for existing apparatus which for NGED’s network requirements is over and above what is necessary as a consequence of and for the purpose of the authorised development, NGED shall reduce the cost of such additional requirements from the amount payable by the undertaker pursuant to sub-paragraph (1). (4) For the purposes of sub-paragraph (3)— (a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the authorised development; and (b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined. (5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit. 48 (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any specified work or any subsidence resulting from any of those works any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of NGED the undertaker is to— (a) bear and pay the cost reasonably incurred by NGED in making good such damage or restoring the supply; and (b) reimburse NGED for any other expenses, loss, damages, penalty or costs reasonably and properly incurred by NGED, by reason or in consequence of any such damage or interruption. (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of NGED, its officers, servants, contractors or agents. (3) NGED must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, is to have the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand. (4) NGED must act reasonably in relation to any claim or demand served under sub-paragraph (1) and use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, claims, demands, proceedings and penalties to which a claim or demand under sub-paragraph (1) applies. (5) NGED’s liability to the undertaker for negligence or breach of contract in respect of each diversion shall be limited to the value of that diversion and NGED shall not otherwise be liable to the undertaker for any losses or costs incurred by the undertaker resulting from delays to the authorised development as a result of its failure to undertake works to deliver any alternative apparatus. Expert determination 49 (1) Article 44 (arbitration) shall apply to any difference as to the legal interpretation of this Part of this Schedule and as provided for in sub-paragraph (7). (2) Save as provided for in sub-paragraph (1) or sub-paragraph (7) any difference under this Part of this Schedule must be referred to and settled by a single independent and suitable person who holds appropriate professional qualifications and is a member of a professional body relevant to the matter in dispute acting as an expert, such person to be agreed by the differing parties or, in the absence of agreement, identified by the President of the Institution of Civil Engineers or the President of the Institution of RICS or the President of the Institution of Engineering and Technology (as relevant and agreed between NGED and the undertaker, both acting reasonably and without delay). (3) All parties involved in settling any difference must use best endeavours to do so within 14 days from the date of a dispute first being notified in writing by one party to the other and in the absence of the difference being settled within that period the expert must be appointed within 21 days of the notification of the dispute. (4) The costs and fees of the expert and the costs of NGED and the undertaker are payable by the parties in such proportions as the expert may determine. In the absence of such determination the costs and fees of the expert are payable equally by the parties who shall each bear their own costs. (5) The expert must— (a) invite the parties to make submissions to the expert in writing and copied to the other party to be received by the expert within 14 days of the expert’s appointment; (b) permit a party to comment on the submissions made by the other party within 7 days of receipt of the submission; (c) issue a decision within 14 days of receipt of the submissions under paragraph (b); and (d) give reasons for the decision. (6) The expert must consider where relevant— (a) the development outcome sought by the undertaker; (b) the ability of the undertaker to achieve its outcome in a timely and cost-effective manner; (c) the nature of the power sought to be exercised by the undertaker; (d) the effectiveness, cost and reasonableness of proposals for mitigation arising from any party; (e) NGED’s service obligations and licence conditions; and (f) any other important and relevant consideration. (7) Any determination by the expert is final and binding, except in the case of manifest error in which case the difference that has been subject to expert determination may be referred to and settled by arbitration under article 44 (arbitration). PART 5 FOR THE PROTECTION OF ANGLIAN WATER Application 50 For the protection of Anglian Water the following provisions have effect, unless otherwise agreed in writing between the undertaker and Anglian Water. Interpretation 51 In this Part of this Schedule— “alternative apparatus” means alternative apparatus adequate to enable Anglian Water to fulfil its statutory functions in a manner no less efficient than previously; “Anglian Water” means Anglian Water Services Limited (company number 02366656) whose registered office is at Lancaster House, Lancaster Way, Ermine Business Park, Huntington, Cambridgeshire PE29 6XU; “apparatus” means— works, mains, pipes or other apparatus belonging to or maintained by Anglian Water for the purposes of water supply and sewerage; any drain or works vested in Anglian Water under the Water Industry Act 1991; any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act; any drainage system constructed for the purpose of reducing the volume of surface water entering any public sewer belonging to Anglian Water; and includes a sludge main, disposal main or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus; and for the purpose of this definition, where words are defined by section 219 of that Act, they must be taken to have the same meaning; “functions” includes powers and duties; “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and “plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed. On street apparatus 52 This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and Anglian Water are regulated by the provisions of Part 3 of the 1991 Act. Apparatus in restricted streets 53 Regardless of the temporary closure, restriction or diversion of any highway under the powers conferred by article 12 (temporary closure, restriction or prohibition of use of streets and public rights of way), Anglian Water is at liberty at all times to take all necessary access across any such temporarily closed highway and to execute and do all such works and things in, upon or under any such highway as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that highway. Protective works to buildings 54 The undertaker, in the case of the powers conferred by article 19 (protective works to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus unless the prior written consent of Anglian Water has been obtained pursuant to paragraph 58 (such consent not to be unreasonably withheld). Acquisition of land 55 Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement, such agreement not to be unreasonably withheld or delayed if the acquisition is required in connection with an approval or consent granted under this Part of this Schedule. Removal of apparatus 56 (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that Anglian Water’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of Anglian Water to maintain that apparatus in that land must not be extinguished, until (a) alternative apparatus has been constructed and is in operation to the reasonable satisfaction of Anglian Water in accordance with sub-paragraphs (2) to (8); and (b) facilities and rights have been secured for that alternative apparatus in accordance with paragraph 57. (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to Anglian Water 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order an undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to Anglian Water the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus. (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed Anglian Water must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed. (4) Any alternative apparatus to be constructed in land of or secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Anglian Water and the undertaker or in default of agreement settled by arbitration in accordance with article 44 (arbitration). (5) Anglian Water must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 44 (arbitration), and after the grant to Anglian Water of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule. (6) Regardless of anything in sub-paragraph (5), if Anglian Water gives notice in writing to the undertaker that it desires the undertaker to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker or to the extent that Anglian Water fails to proceed with that work in accordance with sub-paragraph (5) or the undertaker and Anglian Water otherwise agree, that work, instead of being executed by Anglian Water, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of Anglian Water. (7) If Anglian Water fails either reasonably to approve, or to provide reasons for its failure to approve along with an indication of what would be required to make acceptable, any proposed details relating to required removal works under sub-paragraph (2) within 28 days of receiving a notice of the required works from the undertaker, then such details are deemed to have been approved. For the avoidance of doubt, any such “deemed consent” does not extend to the actual undertaking of the removal works, which must remain the sole responsibility of Anglian Water or its contractors unless the works are to be carried out by the undertaker in accordance with sub-paragraph (6). (8) Whenever alternative apparatus is to be or is being substituted for existing apparatus, the undertaker must, before taking or requiring any further step in such substitution works, use best endeavours to comply with Anglian Water’s reasonable requests for a reasonable period of time to enable Anglian Water to— (a) make network contingency arrangements; or (b) bring such matters as it may consider reasonably necessary to the attention of end users of the utility in question. Facilities and rights for alternative apparatus 57 (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to Anglian Water facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and Anglian Water or in default of agreement settled by arbitration in accordance with article 44 (arbitration). (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to Anglian Water than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to Anglian Water as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. (3) Such facilities and rights as are set out in this paragraph are deemed to include any statutory permits granted to the undertaker or Anglian Water in respect of the apparatus in question, whether under the Environmental Permitting (England and Wales) Regulations 2016 or other legislation. Retained apparatus 58 (1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus (or any means of access to it) the removal of which has not been required by the undertaker under paragraph 56(2), the undertaker must submit to Anglian Water a plan of the works to be executed. (2) Those works must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by Anglian Water for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and Anglian Water is entitled to watch and inspect the execution of those works. (3) Any requirements made by Anglian Water under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan under sub-paragraph (1) is submitted to it. (4) If Anglian Water in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 50 to 52 and 55 to 57 apply as if the removal of the apparatus had been required by the undertaker under paragraph 56(2). (5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan. (6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case must give to Anglian Water notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances, using its best endeavours to keep the impact of those emergency works on Anglian Water’s apparatus, on the operation of its water and sewerage network and on end-users of the services Anglian Water provides to a minimum, save that the undertaker’s obligation to use such best endeavours is subject to the undertaker’s obligation to ensure the safe operation of the authorised development and measures taken by the undertaker to address a danger to life or property must be interpreted as the use of best endeavours. (7) For the purposes of sub-paragraph (1) and without prejudice to the generality of the principles set out in that sub-paragraph, works are deemed to be in land near Anglian Water’s apparatus (where it is a pipe) if those works fall within the following distances measured from the medial line of such apparatus— (a) 4 metres where the diameter of the pipe is less than 250 millimetres; (b) 5 metres where the diameter of the pipe is between 250 and 400 millimetres; and (c) a distance to be agreed on a case by case basis and before the submission of the Plan under sub-paragraph (1) is submitted where the diameter of the pipe exceeds 400 millimetres. Expenses and costs 59 (1) Subject to the following provisions of this paragraph, the undertaker must repay to Anglian Water all expenses reasonably incurred by Anglian Water in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in this Part of this Schedule but always excluding any consequential loss or indirect loss suffered by Anglian Water. (2) There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule that value being calculated after removal. (3) If in accordance with the provisions of this Part of this Schedule— (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 44 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to Anglian Water by virtue of sub-paragraph (1) must be reduced by the amount of that excess. (4) For the purposes of sub-paragraph (3)— (a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined. (5) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraphs 54 or 56(2), or by reason of any subsidence resulting from such development or works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Anglian Water, or there is any interruption in any service provided, or in the supply of any goods, by Anglian Water, the undertaker must— (a) bear and pay the cost reasonably incurred by Anglian Water in making good such damage or restoring the supply; and (b) make reasonable compensation to Anglian Water for any other expenses, loss, damages, penalty or costs incurred by Anglian Water, by reason or in consequence of any such damage or interruption but always excluding any consequential loss or indirect loss arising from such damage or interruption. (6) The fact that any act or thing may have been done by Anglian Water on behalf of the undertaker or in accordance with a plan approved by Anglian Water or in accordance with any requirement of Anglian Water or under its supervision does not, subject to sub-paragraph (7), excuse the undertaker from liability under the provisions of sub-paragraph (1) unless Anglian Water fails to carry out and execute the works properly with due care and attention and in a skilful and professional like manner or in a manner that does not accord with the approved plan. (7) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the unlawful or unreasonable act, neglect or default of Anglian Water, its officers, servants, contractors or agents. (8) Anglian Water must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made, without the consent of the undertaker (such consent not to be unreasonably withheld or delayed) who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand. (9) Anglian Water must use reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands and penalties to which the undertaker must bear and pay the costs for. Cooperation 60 (1) Where in consequence of the proposed construction of any of the authorised development, the undertaker or Anglian Water requires the removal of apparatus under paragraph 56(2) or Anglian Water makes requirements for the protection or alteration of apparatus under paragraph 58, the undertaker must use all reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of Anglian Water’s undertaking, using existing processes where requested by Anglian Water, provided it is appropriate to do so, and Anglian Water must use all reasonable endeavours to co-operate with the undertaker for that purpose. (2) Where the undertaker identifies any apparatus which may belong to or be maintainable by Anglian Water but which does not appear on any statutory map kept for the purpose by Anglian Water, it shall inform Anglian Water of the existence and location of the apparatus as soon as reasonably practicable. (3) Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and Anglian Water in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made. (4) The undertaker and Anglian Water may by written agreement substitute any period of time for those periods set out in this Part of this Schedule. PART 6 FOR THE PROTECTION OF NATIONAL HIGHWAYS Application etc. 61 (1) The provisions of this Part of this Schedule apply for the protection of National Highways and have effect unless otherwise agreed in writing between the undertaker and National Highways. (2) For any part of the strategic road network that is managed under a DBFO contract, both National Highways and the highway operations and maintenance contractor will have the benefit of this Part of this Schedule, save that for the purposes of any approval required under this Part the undertaker must liaise with National Highways. (3) Except where expressly amended by the Order, the operation of the powers and duties of National Highways or the Secretary of State under the 1980 Act, the 1984 Act, the 1991 Act, the Transport Act 2000, or the Town and Country Planning (General Permitted Development) (England) Order 2015 shall continue to apply in respect of the exercise of all statutory functions of National Highways. Interpretation 62 (1) Where the terms defined in article 2 (interpretation) of this Order are inconsistent with sub-paragraph (2) the latter prevail. (2) In this Part of this Schedule— “as built information” means one electronic copy of the following information where National Highways deems it to be necessary and insofar as it is relevant to the works impacting the strategic road network or any land in which National Highways holds an interest— as constructed drawings in both PDF and AutoCAD DWG formats for any road work designed by the undertaker; in compliance with Interim Advice Note 184 or any successor document, and for the cable works, showing the location and depth of the cable as installed and any ancillary or protective measures installed within the strategic road network or land that National Highways has an interest in; list of suppliers and materials used, as well as any relevant test results and CCTV surveys (if required to comply with DMRB standards); product data sheets and technical specifications for all materials used; as constructed information for any utilities discovered or moved during the works; method statements for the works carried out; in relation to road lighting, signs, and traffic signals any information required by Series 1300 and 1400 of the Specification for Highway Works or any replacement or modification of it; organisation and methods manuals for all products used; as constructed programme; test results and records as required by the detailed design information and during construction phase of the project; a stage 3 road safety audit subject to any exceptions to the road safety audit standard as agreed by the undertaker and National Highways; the health and safety file; and such other information, including CCTV surveys, as is required by National Highways to be used to update all relevant databases and to ensure compliance with National Highway’s Asset Data Management Manual or any successor of it as is in operation at the relevant time. “bond” means a bond in the form approved by National Highways duly executed by the undertaker and a reputable UK surety company or other UK financial institution to be previously approved in writing by National Highways (such approval not to be unreasonably withheld or delayed); “the bond sum” means the sum equal to 200% of the cost of carrying out the road works and the cable works (to include all costs plus any commuted sum), or such other sum agreed between the undertaker and National Highways, to be provided to National Highways in the form of— a bond; or a cash surety; or where agreed by National Highways a combination of a bond and cash surety; “cash surety” means a cash deposit to be paid by the undertaker into an account specified by National Highways; “commuted sum” means such sum calculated as provided for in paragraph 73 of this Part of this Schedule to be used to fund the future cost of maintaining any new National Highways assets, structures or apparatus as part of the road works provided under the Order; “cable works” means any works under this Order which consist of the installation and maintenance of cables, cable ducts, tunnels for cables and cable ducts and related or associated works to those operations under the strategic road network or in land in which National Highways has an interest, and to be installed through the use of trenchless installation techniques where no works are required to or on the operational carriageway; “cable works provisional certificate” means the certificate of provisional completion relating to those aspects of the cable works that have resulted in any alteration to the strategic road network to be issued by National Highways in accordance with paragraph 68 when it considers the cable works are substantially complete; “condition survey” means a survey of the condition of National Highways structures and assets that in the reasonable opinion of National Highways may be affected by the road works or cable works which National Highways may require including a CCTV survey of specified drains that National Highways reasonably considers may be materially and adversely affected by the road works or cable works; “contractor” means any contractor or subcontractor appointed by the undertaker to carry out the road works or the cable works or both; “defects period” means the period from the date of the provisional certificate to the date of the final certificate which shall be no less than 12 months from the date of the provisional certificate; “detailed design information” means such of the following drawings specifications and calculations as are relevant to— the road works— site clearance details; boundary, environmental and mitigation fencing; road restraints systems and supporting road restraint risk appraisal process assessment; drainage and ducting as required by DMRB CD 535 Drainage asset data and risk management and DMRB CS551 Drainage surveys – standards for Highways; earthworks including supporting geotechnical assessments required by DMRB CD622 Managing geotechnical risk and any required strengthened earthworks appraisal form certification; pavement, pavement foundations, kerbs, footways and paved areas; traffic signs and road markings; traffic signal equipment and associated signal phasing and timing detail; road lighting (including columns and brackets); regime of California Bearing Ratio testing; electrical work for road lighting, traffic signs and signals; motorway communications as required by DMRB; highway structures and any required structural approval in principle; landscaping; proposed departures from DMRB standards; walking, cycling and horse riding assessment and review report in accordance with DMRB GG142 Designing for walking, cycling and horse riding or any successor document; stage 1 and stage 2 road safety audits and exceptions agreed; utilities diversions; topographical survey; maintenance and repair strategy in accordance with the DMRB GD304 Designing health and safety into maintenance, or any replacement or modification of it; health and safety information including any asbestos survey required by GG105 or any successor document; other such information that may be required by National Highways to be used to inform the detailed design of the road works; and the cable works— earthworks including supporting geotechnical assessments required by DMRB CD622 Managing geotechnical risk or any successor document and any required strengthened earthworks appraisal form certification; health and safety information including any asbestos survey required by GG105 or any successor document; regime of California Bearing Ratio testing; any proposed departures from DMRB standards; apparatus diversions; topographical survey; technical approval of highway structures under CG300 of DMRB; and other such information that may be required by National Highways to be used to inform the detailed design of the cable works; “DBFO contract” means the design build finance operate contract between National Highways and the highway operations and maintenance contractor for the maintenance and operation of parts of the strategic road network which are within the Order Limits or any successor or replacement contract that may be current at the relevant time; “DMRB” means the Design Manual for Roads and Bridges or any replacement or modification of it; “final certificate” means the certificate relating to those aspects of the road works that have resulted in any alteration to the strategic road network to be issued by National Highways pursuant to paragraph 71(2); “the health and safety file” means the file or other permanent record containing the relevant health and safety information for the authorised development required by the Construction Design and Management Regulations 2015 (or such updated or revised regulations as may come into force from time to time); “highway operations and maintenance contractor” means the contractor appointed by National Highways under the DBFO contract; “nominated persons” means the undertaker’s representatives or the contractor’s representatives on site during the carrying out of the cable works or road works as notified to National Highways from time to time; “programme of works” means a document setting out the sequence and timetabling of the cable works or road works; “road safety audit” means an audit carried out in accordance with the road safety audit standard; “road safety audit standard” means DMRB Standard HD GG119 or any replacement or modification of it; “road space booking” means road space bookings in accordance with National Highways’ Asset Management Operational Requirements (AMOR) including Network Occupancy Management System (NOMS) used to manage road space bookings and network occupancy; “road works” means so much of any work including highway works, street works, surveys and signalisation authorised by this Order and including any maintenance of that work, but excluding the cable works, as is undertaken on the strategic road network or land in which National Highways has an interest; “road works provisional certificate” means the certificate of provisional completion relating to those aspects of the road works that have resulted in any alteration to the strategic road network to be issued by National Highways in accordance with paragraph 67 when it considers the road works are substantially complete and, if relevant, may be opened for traffic; “specification for highways works” means the specification, or any successor of it, for highways works forming part of the manual of contract documents for highway works published by National Highways and setting out the requirements and approvals procedures for work, goods or materials used in the construction, improvement or maintenance of the strategic road network; “strategic road network” means any part of the road network including trunk roads, special roads or streets for which National Highways is the highway authority including structures drainage infrastructure, street furniture, verges and vegetation and all other highways assets together with all land, apparatus and rights located in, on, over or under the highway; “utilities” means any pipes, wires, cables or equipment belonging to any person or body having power or consent to undertake street works under the 1991 Act; and “winter maintenance” means maintenance of the road surface to deal with snow and ice. (3) Notwithstanding the grant of development consent in article 3 of the Order, no works in carrying out, maintaining or diverting the authorised development may be carried out in, under or over the strategic road network without the written consent of National Highways pursuant to this Part of this Schedule. (4) References to any standards, manuals, contracts, Regulations and Directives including to specific standards forming part of the DMRB are, for the purposes of this Part of this Schedule, to be construed as a reference to the same as amended, substituted or replaced, and with such modifications as are required in those circumstances. Works outside the Order limits 63 If the undertaker proposes to carry out works to the strategic road network that are outside of the Order Limits in connection with the authorised development, the undertaker must enter into an agreement with National Highways in respect of the carrying out of those works prior to the commencement of those works. Prior approvals 64 (1) The road works must not commence, save to the extent agreed otherwise by National Highways, until— (a) a stage 1 and stage 2 road safety audit has been carried out and all recommendations raised by them or any exceptions are approved by National Highways; (b) the programme of works has been approved by National Highways; (c) the detailed design of the road works comprising the following details, insofar as considered relevant by National Highways, has been submitted to and approved by National Highways— (i) the detailed design information, incorporating all recommendations and any exceptions approved by National Highways under paragraph (a); (ii) details of the proposed road space bookings and the undertaker is entitled to submit its application for road space bookings at the same time as the relevant details are submitted under sub-paragraph (i) to National Highways; (iii) the identity and qualifications of the contractor and nominated persons; and (iv) a process for stakeholder liaison, with key stakeholders to be identified and agreed between National Highways and the undertaker; (d) a scheme of traffic management has been submitted by the undertaker and approved by National Highways such scheme to be capable of amendment by agreement between the undertaker and National Highways from time to time; (e) stakeholder liaison has taken place in accordance with the process for such liaison agreed between the undertaker and National Highways under paragraph (c)(iv) above; (f) National Highways has approved the audit brief and CVs for all road safety audits and exceptions to items raised in accordance with the road safety audit standard; (g) the undertaker has agreed the estimate of the commuted sum with National Highways; (h) the scope of all maintenance operations (routine inspections, incident management, reactive and third party damage) to be carried out by the undertaker during the construction of the road works (which must include winter maintenance) has been agreed in writing by National Highways; (i) the undertaker has procured to National Highways collateral warranties in a form approved by National Highways from the contractor and designer of the road works in favour of National Highways to include covenants requiring the contractor and designer to exercise all reasonable skill care and diligence in designing and constructing the road works, including in the selection of materials, goods, equipment and plant; (j) a condition survey and regime of monitoring has been agreed in writing by National Highways; and (k) any further information that National Highways may reasonably request within 14 days of the submission to National Highways of the detailed design of any road works. (2) The cable works must not commence until— (a) the programme of works has been approved by National Highways; (b) the detailed design of the cable works comprising the following details insofar as is considered relevant by National Highways has been submitted to and approved by National Highways— (i) the detailed design information; (ii) details of the proposed road space bookings and the undertaker is entitled to submit its application for road space bookings at the same time as the relevant details are submitted under sub-paragraph (i) to National Highways; (iii) a method statement including details of the cable works, equipment and location; (c) a survey to determine the appropriate minimum depth for the cable works has been carried out and the minimum cable depth has been approved by National Highways; (d) the detailed design of the cable works including supporting geotechnical assessments required by DMRB CD622 Managing geotechnical risk and any required strengthened earthworks appraisal form certification, has been submitted to and approved by National Highways; (e) a condition survey and regime of monitoring has been agreed in writing by National Highways; (f) the CASS01 has been approved by National Highways; and (g) the undertaker has paid to National Highways the estimate of the NH costs notified to it pursuant to paragraph 66 of this Part of this Schedule; (h) any further information that National Highways may reasonably request within 14 days of the submission to National Highways of the detailed design of any cable works. (3) The undertaker must not, without the consent of National Highways, exercise the powers in— (a) article 5 (power to maintain the authorised development); (b) article 8 (street works); (c) article 10 (power to alter layout, etc., of streets); (d) article 12 (temporary closure, restriction or prohibition of use of streets and public rights of way); (e) article 14 (access to works); (f) article 16 (traffic regulation measures); (g) article 17 (discharge of water); (h) article 19 (protective works to buildings); (i) article 20 (authority to survey and investigate the land); (j) article 21 (compulsory acquisition of land); (k) article 24 (compulsory acquisition of rights); (l) article 27 (power to override easements and other rights); (m) article 29 (acquisition of subsoil only); (n) article 30 (rights under or over streets); (o) article 31 (temporary use of land for constructing the authorised development); (p) article 32 (temporary use of land for maintaining the authorised development); (q) article 40 (felling or lopping of trees and removal of hedgerows), over any part of the strategic road network or land in which National Highways has an interest, and National Highways may, in connection with any such exercise, require the undertaker to provide details of any proposed road space bookings and submit a scheme of traffic management to National Highways for approval. (4) National Highways must, prior to the commencement of the cable works and road works or the exercise of any power referenced in sub-paragraph (3), inform the undertaker of the identity of the person who will act as a point of contact on behalf of National Highways for consideration of the information required under sub-paragraphs (1) and (2). (5) Any approval of National Highways required under this paragraph— (a) must not be unreasonably withheld; (b) must be given in writing; (c) will be deemed to have been refused if neither given nor refused within 2 months of the receipt of the information for approval or where further particulars are requested by National Highways, within 2 months of receipt of the information to which the request for further particulars relates; and (d) may be subject to any conditions as National Highways considers necessary. (6) Any change to the identity of the contractor or designer of the road works or the cable works will be notified to National Highways immediately and details of their suitability to deliver the road works or cable works (as applicable) will be provided on request along with collateral warranties for the road works in a form agreed by National Highways. (7) Any change to the detailed design of the road works or cable works must be approved by National Highways in accordance with sub-paragraphs (1) and (2). (8) Article 47 (procedure in relation to certain approvals etc.) does not apply to any application for consent, agreement or approval required or contemplated by any of the provisions to this Part of this Schedule. Construction of the cable works and road works 65 (1) The undertaker must give National Highways 3 months’ notice in writing of the date on which the cable works and/or road works will start unless otherwise agreed by National Highways. (2) The undertaker must comply with National Highways’ road space booking procedures when booking road space on the strategic road network prior to and during the carrying out the road works or cable works (as applicable) and no road works or cable works for which a road space booking is required may commence without a road space booking having first been secured from National Highways. (3) The cable works and road works must be carried out by the undertaker to the satisfaction of National Highways in accordance with— (a) the relevant detailed design information and programme of works approved pursuant to paragraph 64(1) or 64(2) above or as subsequently varied by agreement between the undertaker and National Highways; (b) the DMRB, the Manual of Contract Documents for Highway Works, including the Specification for Highway Works, together with all other relevant standards as required by National Highways to include, inter alia; all relevant interim advice notes, the Traffic Signs Manual and the Traffic Signs Regulations and General Directions 2016 save to the extent that exceptions from those standards apply which have been approved by National Highways; and (c) all aspects of the Construction (Design and Management) Regulations 2015 (“the CDM Regulations”) or any statutory amendment or variation of the same, and the undertaker will be the client and must ensure that all client duties (as defined in the CDM Regulations) are undertaken to the satisfaction of National Highways. No approval or consent issued by National Highways shall be taken to be a consent or approval pursuant to the CDM Regulations. (4) The undertaker must ensure that, where practicable and without entering the highway, the highway is kept free from mud, soil and litter as a result of carrying out a road work or cable work. (5) The undertaker must permit and must require the contractor to permit at all reasonable times persons authorised by National Highways (whose identity must have been previously notified to the undertaker by National Highways) to gain reasonable access to the cable works and road works for the purposes of inspection and supervision of those works, and to gain reasonable access to land in which National Highways has an interest where access is affected by the cable works or road works or the exercise of the powers in this Order. (6) If any part of the cable works or road works is constructed— (a) other than in accordance with the requirements of this Part of this Schedule; or (b) in a way that causes damage to the highway, highway structure or asset or any other land of National Highways, National Highways may by notice in writing require the undertaker, at the undertaker’s own expense, to comply promptly with the requirements of this Part of this Schedule or remedy any damage notified to the undertaker under this Part of this Schedule, to the satisfaction of National Highways. (7) If during the carrying out of the authorised development the undertaker or its appointed contractors or agents causes damage to the strategic road network then National Highways may by notice in writing require the undertaker, at its own expense, to remedy the damage. (8) If, within 28 days from the day on which a notice under sub-paragraph (6) or (7) is served on the undertaker (or, in the event of there being, in the opinion of National Highways, a danger to road users, within such lesser period as National Highways may stipulate in the notice), the undertaker has failed to take the steps required by that notice, National Highways may carry out the steps required of the undertaker by that notice and may recover from the undertaker any expenditure reasonably incurred by National Highways in so doing, such sum to be payable within 28 days of written demand. (9) Nothing in this Part of this Schedule prevents National Highways from carrying out any work or taking any such action as it reasonably believes to be necessary as a result of or in connection with the carrying out or maintenance of the authorised development without prior notice to the undertaker in the event of an emergency or to prevent the occurrence of danger to the public and National Highways may recover any expenditure it reasonably incurs in so doing (10) In constructing the cable works and road works, the undertaker must at its own expense divert or protect all utilities and all agreed alterations and reinstatement of highway over existing utilities must be constructed to the satisfaction of National Highways. (11) Until such time that National Highways issues the road works provisional certificate, the undertaker must carry out all maintenance (including winter maintenance) in accordance with the scope of maintenance operations agreed by National Highways pursuant to paragraph 64(1)(h) and the undertaker must carry out such maintenance at its own cost. (12) The undertaker must notify National Highways if it fails to complete the road works or cable works in accordance with the agreed programme pursuant to paragraph 64(1)(b) and 64(2)(a) of this Part or suspends the carrying out of any road work or cable work beyond a reasonable period of time and National Highways reserves the right to withdraw any road space booking granted to the undertaker to ensure compliance with its network occupancy requirements. Payments 66 (1) The undertaker must pay to National Highways a sum equal to the costs and expenses which National Highways reasonably and properly incurs (including costs and expenses for using internal or external staff and costs relating to work which becomes abortive) in relation to the cable works and road works and in relation to any approvals sought under this Order, or otherwise incurred under this Part, including— (a) the checking and approval of the information required under paragraphs 64(1) and 64(2); (b) the supervision of the cable works and road works; (c) contractual costs properly payable to the highway operations and maintenance contractor as a consequence of any road works or cable works, including costs incurred by the highway operations and maintenance contractor in carrying out the tasks referred to in paragraphs (a) and (b), in which case National Highways will be responsible for the payment of any sums received from the undertaker under this paragraph to the highway operations and maintenance contractor; (d) the checking and approval of the information required to determine approvals under this Order; (e) all costs relating to the transfer of any land required for the road works or cable works; (f) all legal and administrative costs and disbursements incurred by National Highways in connection with the exercise by the undertaker of the powers in the Order and paragraphs (a) to (c) of this sub-paragraph; and (g) any value added tax which is payable by National Highways in respect of such costs and expenses and for which it cannot obtain reinstatement from HM Revenue and Customs, together comprising “the NH costs”. (2) The undertaker must pay to National Highways upon demand and prior to such costs being incurred the total costs that National Highways believe will be properly and necessarily incurred by National Highways in undertaking any statutory procedure or preparing and bringing into force any traffic regulation order or orders necessary to carry out or for effectively implementing the authorised development. (3) National Highways must provide the undertaker with a schedule showing its estimate of the NH costs prior to the commencement of the cable works and road works. The undertaker must pay to National Highways the estimate of the NH costs prior to commencing the road works or cable works and in any event prior to National Highways incurring any cost. (4) If at any time after the payment referred to in sub-paragraph (3) has become payable, National Highways reasonably believes that the NH costs will exceed the estimated NH costs it may give notice to the undertaker of the amount that it believes the NH costs will exceed the estimate of the NH costs (the excess) and the undertaker must pay to National Highways within 28 days of the date of receipt of a properly issued VAT invoice from National Highways addressed to the undertaker for the excess sum, a sum equal to the excess. (5) National Highways must give the undertaker a final account of the NH costs referred to in sub-paragraph (1) above within 91 days of the issue of both the road works provisional certificate and the cable works provisional certificate issued pursuant to paragraph 67(4) and 68(4). (6) Within 30 days of the issue of the final account— (a) if the final account shows a further sum as due to National Highways the undertaker must pay to National Highways the sum shown due to it; (b) if the account shows that the payment or payments previously made by the undertaker have exceeded the costs incurred by National Highways, National Highways must refund the difference to the undertaker. (7) If any payment due under the provisions of this Part of this Schedule is not made on or before the date on which it falls due, the party from whom it was due must at the same time as making the payment pay to the other party interest at 3% above the Bank of England base lending rate from time to time being in force for the period starting on the date upon which the payment fell due and ending with the date of payment of the sum on which interest is payable together with that interest. Provisional Certificate for road works 67 (1) Following the completion of any road works or prior to the reopening of any part of the strategic road network following any closure or partial closure, whichever is earlier, the undertaker must notify National Highways and National Highways will carry out a site inspection to satisfy itself that the strategic road network is, in its opinion, safe for traffic and the undertaker must comply with any requirements of National Highways following the site inspection. (2) As soon as the undertaker considers that the road works provisional certificate may be properly issued it must apply to National Highways for the road works provisional certificate. (3) Following an application for a road works provisional certificate, National Highways must as soon as reasonably practicable— (a) inspect the road works; and (b) provide the undertaker with a written list of works that are required for the road works provisional certificate to be issued or confirmation that no further works are required for this purpose. (4) When— (a) a stage 3 road safety audit for the road works has been carried out and all recommendations raised including remedial works have (subject to any exceptions agreed) been approved by National Highways; (b) the road works incorporating the approved remedial works under paragraph (a) and any further works notified to the undertaker pursuant to sub-paragraph (3)(b) have been completed to the satisfaction of National Highways; (c) the as built information has been provided to National Highways; and (d) the undertaker has paid the commuted sum to National Highways, National Highways must issue the road works provisional certificate. (5) On the issue of the road works provisional certificate pursuant to this paragraph 67 and the cable works provisional certificate pursuant to paragraph 68 the bond sum shall be reduced to 20% provided that in the event any claim or claims have been made against the undertaker or liability on its part has arisen under the bond sum (which here shall also include any claim or claims to which National Highways are joined howsoever they arise) before that date National Highways will be at liberty to retain a sufficient sum in addition to the 20% to ensure it does not have to meet any costs for and/or arising from and/or in connection with the road works or cable works. (6) The undertaker must submit a stage 4 road safety audits as required by and in line with the timescales stipulated in the road safety audit standard. The undertaker must comply with the findings of the stage 4 road safety audit and must pay all costs of and incidental to such and provide updated as-built information to National Highways. Provisional Certificate for cable works 68 (1) As soon as the undertaker considers that the cable works provisional certificate for the cable works may be properly issued it must apply to National Highways for the cable works provisional certificate. (2) Following an application for a cable works provisional certificate, National Highways must as soon as reasonably practicable— (a) inspect the cable works, the strategic road network, and any land in which National Highways has an interest that is affected by the cable works; and (b) provide the undertaker with a written list of works that are required for the cable works provisional certificate to be issued or confirmation that no further works are required for this purpose. (3) Within 28 days of the completion of any cable works, the undertaker must submit to National Highways the as built information. (4) When the cable works, incorporating any further works notified to the undertaker pursuant to sub-paragraph (2)(b), have been completed to the satisfaction of National Highways and the as built information has been provided to National Highways, National Highways must issue the cable works provisional certificate. (5) The undertaker must make available to National Highways upon request copies of any survey or inspection reports produced pursuant to any inspection or survey of any cable works, following completion of the inspection or survey, that the undertaker may from time to time carry out. Opening 69 Unless otherwise agreed in writing by National Highways the undertaker must notify National Highways not less than 56 days in advance of the intended date of opening to the public of the strategic road network and the undertaker must notify National Highways of the actual date the strategic road network will be opened to the public within 14 days of that date and must not open the strategic road network to the public prior to the expiration of the requisite notice period. Final condition survey 70 (1) The undertaker must, as soon as reasonably practicable after making its application for the road works provisional certificate pursuant to paragraph 67(2) and the cable works provisional certificate pursuant to paragraph 68(1), arrange for any highways structures and assets that were the subject of the condition survey to be re-surveyed and must submit the re-survey to National Highways for its approval. The re-survey will include a renewed geotechnical assessment required by DMRB CD622 for the cable works, road works and any other works beneath the strategic road network. (2) If the re-surveys carried out pursuant to sub-paragraph (1) indicates that any damage has been caused to a structure or asset, the undertaker must submit a scheme for remedial works in writing to National Highways for its approval in writing and the undertaker must carry out the remedial works at its own cost and in accordance with the scheme submitted and such programme as National Highways may require. (3) If the undertaker fails to carry out the remedial work in accordance with the approved scheme and programme or fails to submit a scheme for remedial works to National Highways, National Highways may carry out the steps required of the undertaker and may recover from the undertaker any expenditure it reasonably incurs in so doing. (4) National Highways may, at its discretion, at the same time as giving its approval to the re-surveys pursuant to sub-paragraph (1) give notice in writing that National Highways will remedy any damage identified in the re-surveys and National Highways may recover from the undertaker any expenditure it reasonably incurs in so doing. (5) The undertaker must make available to National Highways upon request copies of any survey or inspection reports produced pursuant to any inspection or survey of any cable work or road work following its completion that the undertaker may from time to time carry out. Defects Period 71 (1) The undertaker must at its own expense remedy any defects in the strategic road network resulting from the carrying out of the road works as are reasonably required by National Highways to be remedied during the defects period. All identified defects must be remedied in accordance with the following timescales— (a) in respect of matters of urgency, within 24 hours of receiving notification for the same (urgency to be determined at the absolute discretion of National Highways); (b) in respect of matters which National Highways considers to be serious defects or faults, within 14 days of receiving notification of the same; and (c) in respect of all other defects notified to the undertaker, within 4 weeks of receiving notification of the same. (2) Following the issuing of the road works provisional certificate, National Highways has responsibility for routine maintenance of the strategic road network save for any soft landscaping works which must be established and which must thereafter be maintained for a period of 3 years by and at the expense of the undertaker. Final Certificate 72 (1) The undertaker must apply to National Highways for the final certificate no sooner than 12 months from the date of the issuing of both the road works provisional certificate and the cable works provisional certificate. (2) Following receipt of the application for the final certificate, National Highways must as soon as reasonably practicable— (a) inspect the strategic road network; and (b) provide the undertaker with a written list of any further works required to remedy or make good any defect or damage in the strategic road network as resulting from the cable works or road works or confirmation that no such works are required for this purpose. (3) The undertaker must carry out such works notified to it pursuant to sub-paragraph (2). (4) When National Highways is satisfied that— (a) any defects or damage arising from defects during the defects period and any defects notified to the undertaker pursuant to sub-paragraph (2) and any remedial works required as a result of any relevant stage 4 road safety audit have been made good to the satisfaction of National Highways; and (b) the NH costs have been paid to National Highways in full; National Highways must issue the final certificate. (5) The bond sum is released in full upon the issue of the final certificate, provided that in the event any claim or claims have been made against the undertaker or liability on its part has arisen under the bond sum (which here will also include any claim or claims to which National Highways are joined howsoever they arise) National Highways will be at liberty to retain a sufficient sum to ensure it does not have to meet any costs for or arising from or in connection with the road works or cable works. (6) The undertaker must pay to National Highways within 28 days of the date of receipt of a properly issued invoice from National Highways addressed to the undertaker, the costs incurred by National Highways in identifying the defects and supervising and inspecting the undertaker’s work to remedy the defects that it is required to remedy pursuant to this paragraph. Security 73 (1) The road works and cable works must not commence until the undertaker procures that the road works and cable works are secured by the bond sum to indemnify National Highways against all losses, damages, costs or expenses arising from any breach of any one or more of the obligations of the undertaker in respect of the exercise of the powers under this Order and road works and cable works under the provisions of this Part of this Schedule. (2) If at any time the undertaker is in breach of these provisions of this Part of this Schedule or becomes insolvent without prejudice to any other remedy National Highways is entitled upon giving notice to the undertaker to use such parts of the bond sum as National Highways considers necessary. For the avoidance of doubt should National Highways have to carry out works pursuant to this Part of this Schedule it may, at its sole discretion, use the bond sum to forward fund such works. Commuted sums 74 (1) National Highways must provide to the undertaker an estimate of the commuted sum, calculated in accordance with Commuted Lump Sum A Guide for Promoters of Major Third Party Projects dated 28 November 2023 or any successor guidance, prior to the commencement of the road works. (2) The undertaker must pay to National Highways the commuted sum prior to the issue of the road works provisional certificate. Insurance 75 Prior to the commencement of the cable works and road works the undertaker must effect public liability insurance with an insurer in the minimum sum of £50,000,000.00 (fifty million pounds) in respect of any one claim against any legal liability for damage loss or injury to any property or any person as a direct result of the execution of the cable works or road works or use of the strategic road network by the undertaker. Indemnity 76 The undertaker fully indemnifies National Highways from and against all costs, claims, expenses, damages, losses and liabilities suffered by National Highways arising from, or in connection to the construction, maintenance or use of the road works and cable works, or exercise of or failure to exercise any power under this Order and any such costs shall be paid to National Highways within 14 days of demand save for any loss arising out of or in consequence of any negligent act or default of National Highways. Maintenance of the authorised development 77 (1) The undertaker must, prior to the commencement of any works of maintenance to the cable works or road works, give National Highways 28 days’ notice in writing of the date on which those works will start unless otherwise agreed by National Highways, acting reasonably. (2) If, for the purposes of maintaining the cable works or road works, the undertaker needs to occupy any road space, the undertaker must comply with National Highways’ road space booking requirements and no maintenance of any works for which a road space booking is required may commence without a road space booking having first been secured. (3) During any maintenance works, the undertaker must comply with any requirements that National Highways may notify to the undertaker, such requirements to be notified to the undertaker not less than 7 days’ in advance of the planned commencement date of the maintenance works. (4) The provisions of paragraph 69 shall apply to the opening of any part of the strategic road network following occupation of any road space under this paragraph. Land 78 (1) Following the issue of the final certificate pursuant to paragraph 72(4) National Highways may serve notice on the undertaker that it wishes to take a freehold transfer of land within the extent of strategic road network boundary which is not in the ownership of National Highways but has been acquired by the undertaker for the purposes of carrying out the road works. (2) If the undertaker receives notice under sub-paragraph (1) then the undertaker must effect a freehold transfer of the land which is the subject of the notice and complete such transfer as soon as reasonably practicable at no cost to National Highways. (3) The undertaker must not exercise the powers of this Order over any land forming part of the strategic road network or land owned by National Highways, other than with the consent of National Highways (such consent not to be unreasonably withheld and delayed), so as to— (a) acquire or use the land; (b) acquire new or existing rights in the land; (c) impose or extinguish any restrictive covenant over the land; (d) extinguish any existing rights held by National Highways; or (e) interfere with the apparatus of National Highways. (4) A consent under sub-paragraph (3) must be requested in writing by email to legalservicesinbox@nationalhighways.co.uk. Expert Determination 79 (1) Article 44 (arbitration) of the Order does not apply to this Part of this Schedule. (2) Any difference under this Part of this Schedule may be referred to and settled by a single independent and suitable person who holds appropriate professional qualifications and is a member of a professional body relevant to the matter in dispute acting as an expert, such person to be agreed by the differing parties or, in the absence of agreement, identified by the President of the Institution of Civil Engineers. (3) On notification by either party of a dispute, the parties must jointly instruct an expert within 14 days of notification of the dispute. (4) All parties involved in settling any difference must use best endeavours to do so within 21 days from the date that an expert is appointed. (5) The expert must— (a) invite the parties to make submission to the expert in writing and copied to the other party to be received by the expert within 7 days of the expert’s appointment; (b) permit a party to comment on the submissions made by the other party within 7 days of receipt of the submission; (c) issue a decision within 7 days of receipt of the submissions under paragraph (b); and (d) give reasons for the decision. (6) Any determination by the expert is final and binding, except in the case of manifest error in which case the difference that has been subject to expert determination may be referred to and settled by arbitration under article 44 (arbitration). (7) The fees of the expert are payable by the parties in such proportions as the expert may determine or, in the absence of such determination, equally. PART 7 FOR THE PROTECTION OF THE ENVIRONMENT AGENCY 80 (1) The following provisions apply for the protection of the Agency unless otherwise agreed in writing between the undertaker and the Agency. (2) In this part of this Schedule— “Agency” means the Environment Agency; “construction” includes execution, placing, altering, replacing, relaying and removal and excavation and “construct” and “constructed” is construed accordingly; “drainage work” means any main river and includes any land which provides or is expected to provide flood storage capacity for any main river and any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage, flood defence or tidal monitoring; “emergency” means an occurrence which presents a risk of— serious flooding; serious detrimental impact on drainage; serious harm to the environment; “fishery” means any waters containing fish and fish in, or migrating to or from, such waters and the spawn, spawning ground, habitat or food of such fish; “main river” has the same meaning given in section 113 of the Water Resources Act 1991; “non-tidal main river” has the meaning given in paragraph 2(1) of Part 1 of Schedule 25 to the Environmental Permitting (England and Wales) Regulations 2016; “plans” includes plans, sections, elevations, drawings, specifications, programmes, proposals, calculations, method statements and descriptions; “remote defence” means any berm, wall or embankment that is constructed for the purposes of preventing or alleviating flooding from, or in connection with, any main river; “sea defence” means any bank, wall, embankment (any berm, counterwall or cross-wall connected to any such bank, wall or embankment), barrier, tidal sluice and other defence, whether natural or artificial, against the inundation of land by sea water or tidal water, including natural or artificial high ground which forms part of or makes a contribution to the efficiency of the defences of the Agency’s area against flooding, but excludes any sea defence works which are for the time being maintained by a coast protection authority under the provisions of the Coast Protection Act 1949 or by any local authority or any navigation, harbour or conservancy authority; “specified work” means so much of any work or operation authorised by this Order as is in, on, under, over or within; 16 metres of the base of a sea defence which is likely to— endanger the stability of, cause damage or reduce the effectiveness of that sea defence, or interfere with the Agency’s access to or along that sea defence or the Agency’s ability to undertake works to ensure the efficacy of that sea defence; 8 metres of the base of a remote defence which is likely to— endanger the stability of, cause damage or reduce the effectiveness of that remote defence, or interfere with the Agency’s access to or along that remote defence; 16 metres of a drainage work involving a tidal main river; 8 metres of a drainage work involving a non-tidal main river; any distance of a drainage work and is otherwise likely to— affect any drainage work or the volumetric rate of flow of water in or flowing to or from any drainage work; affect the flow, purity or quality of water in any main river or other surface waters; cause obstruction to the free passage of fish or damage to any fishery; affect the conservation, distribution or use of water resources; or affect the conservation value of the main river and habitats in its immediate vicinity; or which involves— an activity that includes dredging, raising or taking of any sand, silt, ballast, clay, gravel or other materials from or off the bed or banks of a drainage work (or causing such materials to be dredged, raised or taken), including hydrodynamic dredging or desilting; and any quarrying or excavation within 16 metres of a drainage work which is likely to cause damage to or endanger the stability of the banks or structure of that drainage work; “tidal main river” has the meaning given in paragraph 2(1) of Part 1 of Schedule 25 to the Environmental Permitting (England and Wales) Regulations 2016. Submission and approval of plans 81 (1) Before beginning to construct any specified work, the undertaker must submit to the Agency plans of the specified work and such further particulars available to it as the Agency may within 28 days of the receipt of the plans reasonably request. (2) Any such specified work must not be constructed except in accordance with such plans as may be approved in writing by the Agency, or determined under paragraph 91. (3) Any approval of the Agency required under this paragraph— (a) must not be unreasonably withheld or delayed; (b) subject to sub-paragraph (5), is deemed to have been refused if it is neither given nor refused within 2 months of the submission of the plans or such later date as is agreed between the Agency and the undertaker and if further particulars have been requested pursuant to sub-paragraph (1) the period between the making of this request and the provision of further particulars in response to it shall not be taken into account in the calculation of the 2 months for the purposes of this sub-paragraph; and (c) may be given subject to such reasonable requirements as the Agency may have for the protection of any drainage work or the fishery or for the protection of water resources, or for the prevention of flooding or pollution or for nature conservation or the prevention of environmental harm in the discharge of its environmental duties. (4) The Agency must use its reasonable endeavours to respond to the submission of any plans before the expiration of the period mentioned in sub-paragraph (3)(b). (5) In the case of a refusal, the Agency must provide reasons for the grounds of that refusal. Construction of protective works 82 Without limiting paragraph 81 the requirements which the Agency may have under that paragraph include conditions requiring the undertaker, at its own expense, to construct such protective works, whether temporary or permanent, before or during the construction of the specified works (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary— (a) to safeguard any drainage work against damage; or (b) to secure that its efficiency for flood defence purposes is not impaired and that the risk of flooding is not otherwise increased, by reason of any specified work. Timing of works and service of notices 83 (1) Subject to sub-paragraph (2), any specified work, and all protective works required by the Agency under paragraph 82, must be constructed— (a) without unreasonable delay in accordance with the plans approved under this Part of this Schedule; and (b) to the reasonable satisfaction of the Agency, and the Agency is entitled by its officer to watch and inspect the construction of such works. (2) The undertaker must give to the Agency not less than 14 days’ notice in writing of its intention to commence construction of any specified work and notice in writing of its completion not later than 7 days after the date on which it is completed. (3) If the Agency reasonably requires, the undertaker must construct all or part of the protective works so that they are in place prior to the construction of any specified work to which the protective works relate. Works not in accordance with this Schedule 84 (1) If there is any failure by the undertaker to obtain consent or comply with conditions imposed by the Agency in accordance with these protective provisions and where the Agency acting reasonably considers it necessary to avoid any of the risks specified in sub-paragraph (2), the Agency may serve written notice requiring the undertaker to cease all or part of the specified works as may be specified within the notice within the period specified in the notice, and the undertaker must cease constructing the specified works or part thereof until such time as it has obtained the consent or complied with the condition specified within the notice served. (2) The risks specified in sub-paragraph (1) are— (a) risk of flooding; (b) risk of harm to the environment; (c) risk of detrimental impact on drainage; (d) damage to the fishery. (3) If any part of a specified work or any protective work required by the Agency is constructed otherwise than in accordance with the requirements of this Part of this Schedule, the Agency may by notice in writing require the undertaker at the undertaker’s own expense to comply with the requirements of this Part of this Schedule or (if the undertaker so elects and the Agency in writing consents, such consent not to be unreasonably withheld or delayed) to remove, alter or pull down the work and, where removal is required, to restore the site to its former condition to such extent and within such limits as the Agency reasonably requires. (4) Subject to sub-paragraph (5), if, within a reasonable period, being not less than 28 days beginning with the date when a notice under sub-paragraph (3) is served upon the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, the Agency may execute the works specified in the notice and any reasonable expenditure incurred by the Agency in so doing is recoverable from the undertaker. (5) In the event of any dispute as to whether sub-paragraph (3) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the Agency must not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (4) until the dispute has been finally determined in accordance with paragraph 91. Maintenance of works 85 (1) Subject to sub-paragraph (5) the undertaker must from the commencement of the construction of the specified works maintain in good repair and condition and free from obstruction any drainage work which is situated within the limits of deviation and on land held by the undertaker for the purposes of or in connection with the specified works, whether or not the drainage work is constructed under the powers conferred by this Order or is already in existence. (2) If any such drainage work which the undertaker is liable to maintain is not maintained to the reasonable satisfaction of the Agency, the Agency may by notice in writing require the undertaker to repair and restore the work, or any part of such work, or (if the undertaker so elects and the Agency in writing consents, such consent not to be unreasonably withheld or delayed), to remove the work and restore the site to its former condition, to such extent and within such limits as the Agency reasonably requires. (3) Subject to sub-paragraph (4) if, within a reasonable period, being not less than 28 days beginning with the date on which a notice in respect of any drainage work is served under sub-paragraph (2) on the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, the Agency may do what is necessary for such compliance and any reasonable expenditure incurred by the Agency in so doing is recoverable from the undertaker. (4) In the event of any dispute as to the reasonableness of any requirement of a notice served under sub-paragraph (2), the Agency must not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (3) until the dispute has been finally determined in accordance with paragraph 91. (5) This paragraph does not apply to— (a) drainage works which are vested in the Agency, or which the Agency or another person is liable to maintain and is not proscribed by the powers of the Order from doing so; and (b) any obstruction of a drainage work expressly authorised in the approval of specified works plans and carried out in accordance with the provisions of this Part provided that any obstruction is removed as soon as reasonably practicable. Remediating impaired drainage work 86 If by reason of the construction of any specified work or of the failure of any such work, the efficiency of any drainage work for flood defence purposes is impaired, or that drainage work is otherwise damaged, such impairment or damage must be made good by the undertaker to the reasonable satisfaction of the Agency and if the undertaker fails to do so, the Agency may make good the impairment or damage and recover any expenditure incurred by the Agency in so doing from the undertaker. Agency access 87 If by reason of the construction of any specified work or the failure of any such work, the Agency’s access to flood defences or equipment maintained for flood defence purposes is materially obstructed, the undertaker must notify the Agency immediately and provide suitable alternative means of access that will allow the Agency to maintain the flood defence or use the equipment no less effectively than was possible before the obstruction occurred and such alternative access must be made available as soon as reasonably practicable after the undertaker becomes aware of such obstruction, except in the case of an emergency in which case the undertaker must provide such alternative means of access on demand. Free passage of fish 88 (1) The undertaker must take all such measures as may be reasonably practicable to prevent any interruption of the free passage of fish in the fishery during the construction of any specified work. (2) If by reason of— (a) the construction of any specified work; or (b) the failure of any such work, damage to the fishery is caused, or the Agency has reason to expect that such damage may be caused, the Agency may serve notice on the undertaker requiring it to take such steps as may be reasonably practicable to make good the damage, or, as the case may be, to protect the fishery against such damage within the period specified in the notice. (3) If, the undertaker fails to take such steps as are described in the notice served under sub-paragraph (2), the Agency may take those steps and any expenditure incurred by the Agency in so doing is recoverable from the undertaker. (4) In any case where immediate action by the Agency is reasonably required in order to secure that the risk of damage to the fishery is avoided or reduced, the Agency may take such steps as are reasonable for the purpose, and may recover from the undertaker any expenditure incurred in so doing provided that notice specifying those steps is served on the undertaker as soon as reasonably practicable after the Agency has taken, or commenced to take, the steps specified in the notice. Indemnity 89 The undertaker indemnifies the Agency in respect of all costs, charges and expenses which the Agency may incur— (a) in the examination or approval of plans under this Part of this Schedule; (b) in the inspection of the construction of the specified works or any protective works required by the Agency under this Part of this Schedule; and (c) in the carrying out of any surveys or tests by the Agency which are reasonably required in connection with the construction of the specified works. 90 (1) The undertaker is responsible for and indemnifies the Agency against all costs and losses, liabilities, claims and demands not otherwise provided for in this Schedule which may be reasonably incurred or suffered by the Agency by reason of, or arising out of— (a) the construction, operation or maintenance of any specified works comprised within the authorised development or the failure of any such works comprised within them; or (b) any act or omission of the undertaker, its employees, contractors or agents or others whilst engaged upon the construction, operation or maintenance of the authorised development or dealing with any failure of the authorised development. (2) For the avoidance of doubt, in sub-paragraph (1)— “costs” includes— expenses and charges; staff costs and overheads; legal costs; “losses” includes physical damage. “claims” and “demands” include as applicable— costs (within the meaning of this sub-paragraph) incurred in connection with any claim or demand; any interest element of sums claimed or demanded; “liabilities” includes— contractual liabilities; tortious liabilities (including liabilities for negligence or nuisance); liabilities to pay statutory compensation or for breach of statutory duty; and liabilities to pay statutory penalties imposed on the basis of strict liability (but does not include liabilities to pay other statutory penalties). (3) The Agency must give to the undertaker reasonable notice of any such claim or demand and must not settle or compromise a claim without the agreement of the undertaker and that agreement must not be unreasonably withheld or delayed. (4) The Agency must, at all times take reasonable steps to prevent and mitigate any such claims, demands, proceedings, costs, damages, expenses or loss. (5) The fact that any work or thing has been executed or done by the undertaker in accordance with a plan approved by the Agency, or to its satisfaction, or in accordance with any directions or award of an arbitrator, must not relieve the undertaker from any liability under the provisions of this Part of this Schedule. (6) Nothing in this paragraph imposes any liability on the undertaker with respect to any costs, charges, expenses, damages, claims, demands or losses to the extent that they are attributable to the neglect or default of the Agency, its officers, servants, contractors or agents. Disputes 91 Any dispute arising between the undertaker and the Agency under this Part of this Schedule must, if the parties agree, be determined by arbitration under article 44 (arbitration), but failing agreement be determined by the Secretary of State for Environment, Food and Rural Affairs or its successor and the Secretary of State for Energy Security and Net Zero or its successor acting jointly on a reference to them by the undertaker or the Agency, after notice in writing by one to the other. PART 8 FOR THE PROTECTION OF CADENT GAS LIMITED Application 92 For the protection of Cadent the following provisions will, unless otherwise agreed in writing between the undertaker and Cadent, have effect. Interpretation 93 In this Part of this Schedule— “alternative apparatus” means appropriate alternative apparatus to the reasonable satisfaction of Cadent to enable Cadent to fulfil its statutory functions in a manner no less efficient than previously; “apparatus” means any gas mains, pipes, pressure governors, ventilators, cathodic protections (including transformed rectifiers and any associated groundbeds or cables), cables, marker posts, block valves, hydrogen above ground installations or other apparatus belonging to, or maintained by, Cadent for the purposes of Cadent’s undertaking together with any replacement apparatus and such other apparatus constructed pursuant to this Order that becomes operational apparatus of Cadent for the purposes of Cadent’s undertaking and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus; “authorised works” has the same meaning as is given to the term “authorised development” in article 2 of this Order and for the purposes of this Part of this Schedule includes the use and maintenance of the authorised works and construction of any works authorised by this Schedule; “Cadent” means Cadent Gas Limited (company number 10080864) whose registered office is at Cadent, Pilot Way, Ansty, Coventry, England, CV7 9JU, and includes its successors in title or any successor as a gas transporter within the meaning of Part 1 of the Gas Act 1986; “Cadent’s undertaking” means the rights, duties and obligations of Cadent Gas Limited as a public gas transporter within the meaning of Section 7 of the Gas Act 1986 (as amended by the Gas Act 1995); “commence” has the same meaning as in article 2 of this Order and “commencement” will be construed to have the same meaning save that, for the purposes of this Part of this Schedule only, the terms “commence” and “commencement” include operations for the purposes of intrusive archaeological investigations and intrusive investigations of the existing condition of the ground or of structures within 15 metres in any direction of Cadent’s apparatus; “deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, enactments and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule; “functions” includes powers and duties; “ground mitigation scheme” means a scheme approved by Cadent (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event; “ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, must require the undertaker to submit for Cadent’s approval a ground mitigation scheme; “ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme; “in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land; “maintain” and “maintenance” will include the ability and right to do any of the following in relation to any apparatus or alternative apparatus of Cadent including retain, lay, construct, inspect, maintain, protect, use, access, enlarge, replace, renew, remove, decommission or render unusable or remove the apparatus; “plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary to properly and sufficiently describe and assess the works to be executed; “rights” includes rights and restrictive covenants and, in relation to decommissioned apparatus, the surrender of rights, release of liabilities and transfer of decommissioned apparatus; and “specified works” means any of the authorised works or activities (including maintenance) undertaken in association with the authorised works which— will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph 98(2) or otherwise; may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under paragraph 98(2) or otherwise; or include any of the activities that are referred to in CD/SP/SSW/22 (Cadent’s Specification for Safe Working in the Vicinity of Cadent Assets). On street apparatus 94 (1) Except for— (a) paragraph 95 (apparatus of Cadent in stopped up streets); (b) paragraph 98 (removal of apparatus) insofar as sub-paragraph (2) applies; (c) paragraph 99 (facilities and rights for alternative apparatus) in so far as sub-paragraph (2) applies; (d) paragraph 100 (retained apparatus: protection of Cadent); (e) paragraph 101 (expenses); and (f) paragraph 102 (indemnity), of this Part of this Schedule which will apply in respect of the exercise of all or any powers under the Order affecting the rights and apparatus of Cadent, the other provisions of this Part of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and Cadent are regulated by the provisions of Part 3 of the 1991 Act. (2) Paragraphs 98 and 99 of this Part of this Schedule will apply to diversions even where carried out under the 1991 Act, in circumstances where any apparatus is diverted from an alignment within the existing adopted public highway but not wholly replaced within existing adopted public highway. (3) Notwithstanding article 12 (temporary closure, restriction or prohibition of use of streets and public rights of way) or any other powers in the Order generally, section 85 of the 1991 Act in relation to cost sharing and the regulations made thereunder will not apply in relation to any diversion of apparatus of Cadent under the 1991 Act. Apparatus of Cadent in closed streets 95 (1) Notwithstanding the temporary closure, restriction or prohibition of use of any street under the powers of article 12 (temporary closure, restriction or prohibition of use of streets and public rights of way), Cadent will be at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as it would have been entitled to do immediately before such temporary closure or restriction in respect of any apparatus which at the time of the closure, restriction or prohibition was in that street. (2) The protective provisions in this Part of this Schedule apply and take precedence over article 34 (apparatus and rights of statutory undertakers in closed or restricted streets) which shall not apply to Cadent. Protective works to buildings 96 (1) The undertaker, in the case of the powers conferred by article 19 (protective works to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus without the written consent of Cadent and, if by reason of the exercise of those powers any damage to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal or abandonment) or property of Cadent or any interruption in the supply of gas by Cadent, as the case may be, is caused, the undertaker must bear and pay on demand the cost reasonably incurred by Cadent in making good such damage or restoring the supply; and, subject to sub-paragraph (2), will— (a) pay compensation to Cadent for any loss sustained by it; and (b) indemnify Cadent against all claims, demands, proceedings, costs, damages and expenses which may be made or taken against or recovered from or incurred by Cadent, by reason of any such damage or interruption. (2) Nothing in this paragraph imposes any liability on the undertaker with respect to any damage or interruption to the extent that such damage or interruption is attributable to the act, neglect or default of Cadent or its contractors or workers; and Cadent will give to the undertaker reasonable notice of any claim or demand as aforesaid and no settlement or compromise thereof shall be made by Cadent, save in respect of any payment required under a statutory compensation scheme, without first consulting the undertaker and giving the undertaker an opportunity to make representations as to the claim or demand. Acquisition of land 97 (1) Regardless of any provision in this Order or anything shown on the land plan or contained in the book of reference to the Order, the undertaker may not appropriate or acquire any interest in land or appropriate, acquire, extinguish, interfere with or override any easement, other interest or right or apparatus in land of Cadent otherwise than by agreement. (2) As a condition of agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised works (or in such other timeframe as may be agreed between Cadent and the undertaker) that are subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of Cadent or affects the provisions of any enactment or agreement regulating the relations between Cadent and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as Cadent reasonably requires enter into such deeds of consent and variations upon such terms and conditions as may be agreed between Cadent and the undertaker acting reasonably and which must be no less favourable on the whole to Cadent unless otherwise agreed by Cadent, and the undertaker shall use reasonable endeavours to procure and secure the consent to and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works. (3) The undertaker and Cadent agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation or removal of apparatus, including but not limited to the payment of costs and expenses relating to such relocation or removal of apparatus and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by Cadent or other enactments relied upon by Cadent as of right or other use in relation to the apparatus, then the provisions in this Part of this Schedule will prevail. (4) Any agreement or consent granted by Cadent under paragraph 100 or any other paragraph of this Part of this Schedule, will not be taken to constitute agreement under sub-paragraph (1). (5) As a condition of an agreement under sub-paragraph (1) that involves decommissioned apparatus being left in situ in land owned by the undertaker, the undertaker must accept a surrender of any existing easement or other interest of Cadent in such decommissioned apparatus and consequently acquire title to such decommissioned apparatus and release Cadent from all liabilities in respect of such decommissioned apparatus from the date of such surrender but excluding any liabilities that exist prior to the date of such surrender. (6) Where the undertaker acquires the freehold of any land which is subject to any Cadent right or interest (including, without limitation, easements and agreements relating to rights or other interests) and the provisions of paragraph 99 do not apply, the undertaker must— (a) retain any notice of Cadent’s easement, right or other interest on the title to the relevant land when registering the undertaker’s title to such acquired land; and (b) (where no such notice of Cadent’s easement, right or other interest exists in relation to such acquired land or any such notice is registered only on the Land Charges Register) include (with its application to register title to the undertaker’s interest in such acquired land at the Land Registry) a notice of Cadent’s easement, right or other interest in relation to such acquired land. Removal of apparatus 98 (1) If, in the exercise of any agreement reached in accordance with paragraph 97, or in any other authorised manner, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus must not be decommissioned or removed under this Part of this Schedule and any right of Cadent to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, is in operation, and the facilities and rights referred to in sub-paragraph (2) have been provided, to the satisfaction of Cadent and in accordance with sub-paragraphs (2) to (5) inclusive. (2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to Cadent advance written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order Cadent reasonably needs to move or remove any of its apparatus) the undertaker must afford to Cadent to its satisfaction (taking into account paragraph 99(1)) the necessary facilities and rights— (a) for the construction of alternative apparatus (including appropriate working areas required to reasonably and safely undertake necessary works by Cadent in respect of the apparatus); (b) subsequently for the maintenance of that apparatus (including appropriate working areas required to reasonably and safely undertake necessary works by Cadent in respect of the apparatus); and (c) to allow access to that apparatus (including appropriate working areas required to reasonably and safely undertake necessary works by Cadent in respect of the apparatus). (3) If the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, Cadent may, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to assist the undertaker in obtaining the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation will not extend to the requirement for Cadent to use its compulsory purchase powers to this end unless it (in its absolute discretion) elects to so do. (4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Cadent and the undertaker or settled by arbitration. (5) Cadent must, after the alternative apparatus to be provided or constructed has been agreed or settled, and subject to the prior grant to Cadent of such facilities and rights as are referred to in sub-paragraph (2) or (3) have been afforded to Cadent to its satisfaction, then proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to decommission or remove any apparatus required by the undertaker to be decommissioned or removed under the provisions of this Part of this Schedule. Facilities and rights for alternative apparatus 99 (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for Cadent facilities and rights in land for the access to, or construction and maintenance of alternative apparatus in substitution for apparatus to be decommissioned or removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and Cadent and must be no less favourable on the whole to Cadent than the facilities and rights enjoyed by it in respect of the apparatus to be decommissioned or removed unless otherwise agreed by Cadent. (2) If the facilities and rights to be afforded by the undertaker and agreed with Cadent under sub-paragraph (1) in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to Cadent than the facilities and rights enjoyed by it in respect of the apparatus to be decommissioned or removed (in Cadent’s opinion, acting reasonably), then the terms and conditions to which those facilities and rights are subject in the matter will be referred to arbitration in accordance with paragraph 106 (arbitration) of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to Cadent as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. Retained apparatus: protection of Cadent 100 (1) Not less than 56 days (or such time period as may be agreed in writing between Cadent and the undertaker) before the commencement of any specified works the undertaker must submit to Cadent a plan and, if reasonably required by Cadent, a ground monitoring scheme in respect of those works. (2) The plan to be submitted to Cadent under sub-paragraph (1) must include a method statement and describe— (a) the exact position of the works; (b) the level at which these are proposed to be constructed or renewed; (c) the manner of their construction or renewal including details of excavation, positioning of plant etc.; (d) the position of all apparatus; (e) by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus; and (f) any intended maintenance regimes. (3) The undertaker must not commence any specified works until Cadent has given written approval of the plan so submitted (and the ground monitoring scheme if required). (4) Any approval of Cadent required under sub-paragraph (3)— (a) may be given subject to reasonable conditions for any purpose mentioned in sub-paragraph (5) or (7); and (b) must not be unreasonably withheld or delayed. (5) In relation to any specified works to which sub-paragraph (1) applies, Cadent may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage or for the purpose of providing or securing proper and convenient means of access to any apparatus. (6) Works to which this paragraph applies must only be executed in accordance with— (a) the plan submitted under sub-paragraphs (1) and (2) or as relevant sub-paragraph (5), as approved or as amended from time to time by agreement between the undertaker and Cadent; and (b) all conditions imposed under sub-paragraph (4)(a), and Cadent will be entitled to watch and inspect the execution of those works where reasonably practicable to do so and in accordance with any relevant health and safety legislation. (7) Where Cadent requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to Cadent’s satisfaction prior to the commencement of any specified works (or any relevant part thereof) for which protective works are required prior to commencement. (8) If Cadent, in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 92 to 94 and 97 to 99 apply as if the removal of the apparatus had been required by the undertaker under sub-paragraph 98(2) provided that such written notice must be given by Cadent to the undertaker no later than as part of the approval of a plan submitted pursuant to sub-paragraph (1). (9) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the specified works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph will apply to and in respect of the new plan. (10) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to Cadent notice as soon as is reasonably practicable and a plan of those works and must comply with— (a) the conditions imposed under sub-paragraph (4)(a) insofar as is reasonably practicable in the circumstances; and (b) sub-paragraph (11) at all times. (11) At all times when carrying out any works authorised under the Order the undertaker must comply with the Cadent’s policies for safe working in proximity to gas apparatus “Specification for Safe Working in the Vicinity of Cadent Assets CAD//SP/SSW/22” and HSE’s “HS(~G)47 Avoiding Danger from underground services”. (12) As soon as reasonably practicable after any ground subsidence event attributable to the authorised works the undertaker must implement an appropriate ground mitigation scheme save that Cadent retains the right to carry out any further necessary protective works for the safeguarding of its apparatus and can recover any such costs in line with paragraph 101. Expenses 101 (1) Subject to the following provisions of this paragraph, the undertaker must pay to Cadent on demand all charges, costs and expenses reasonably anticipated or incurred by Cadent in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised works as are referred to in this Part of this Schedule including without limitation— (a) any costs reasonably incurred by or compensation properly paid by Cadent in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs (including professional fees) incurred by Cadent as a consequence of Cadent— (i) using its own compulsory purchase powers to acquire any necessary rights under sub-paragraph 98(3) if it elects to do so; or (ii) exercising any compulsory purchase powers in the Order transferred to or benefitting Cadent; (b) in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus; (c) the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus; (d) the approval of plans; (e) the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works; (f) the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule; (g) any watching brief pursuant to sub-paragraph 100(6). (2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal. (3) If in accordance with the provisions of this Part of this Schedule— (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 106 to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to Cadent by virtue of sub-paragraph (1) will be reduced by the amount of that excess save where it is not possible or appropriate in the circumstances (including due to statutory or regulatory changes) to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker. (4) For the purposes of sub-paragraph (3)— (a) an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined. (5) An amount which apart from this sub-paragraph would be payable to Cadent in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on Cadent any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit. Indemnity 102 (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works authorised by this Part of this Schedule (including without limitation relocation, diversion, decommissioning, construction and maintenance of apparatus or alternative apparatus) or in consequence of the construction, use, maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by the undertaker) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised works) or property of Cadent, or there is any interruption in any service provided, or in the supply of any goods, by Cadent, or Cadent becomes liable to pay any amount to any third party, the undertaker will— (a) bear and pay on demand, accompanied by an invoice or claim from Cadent, the cost reasonably incurred by Cadent in making good such damage or restoring the supply; and (b) indemnify Cadent for any other expenses, loss, demands, proceedings, damages, claims, penalty, or costs incurred by or recovered from Cadent, by reason or in consequence of any such damage or interruption or Cadent becoming liable to any third party as aforesaid other than arising from any negligence or default of Cadent. (2) The fact that any act or thing may have been done by Cadent on behalf of the undertaker or in accordance with a plan approved by Cadent or in accordance with any requirement of Cadent or under its supervision including under any watching brief will not (unless sub-paragraph (3) applies) excuse the undertaker from liability under the provisions of this sub-paragraph (1) unless Cadent fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan or in a manner as may otherwise be agreed between the undertaker and Cadent. (3) Nothing in sub-paragraph (1) will impose any liability on the undertaker in respect of— (a) any damage or interruption to the extent that it is attributable to the neglect or default of Cadent, its officers, servants, contractors or agents; and (b) any authorised works or any other works authorised by this Part of this Schedule carried out by Cadent as an assignee, transferee or lessee of the undertaker with the benefit of the Order pursuant to section 156 of the 2008 Act or article 37 (consent to transfer the benefit of the Order) of the Order subject to the proviso that once such works become apparatus (“new apparatus”), any authorised works yet to be executed and not falling within this paragraph (b) will be subject to the full terms of this Part of this Schedule including this paragraph in respect of such new apparatus. (4) Cadent must give the undertaker reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering its representations. Enactments and agreements 103 Save to the extent provided for to the contrary elsewhere in this Part of this Schedule or by agreement in writing between Cadent and the undertaker, nothing in this Part of this Schedule will affect the provisions of any enactment or agreement regulating the relations between the undertaker and Cadent in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made. Co-operation 104 (1) Where in consequence of the proposed construction of any part of the authorised works, the undertaker or Cadent requires the removal of apparatus under paragraph 98(2) or Cadent makes requirements for the protection or alteration of apparatus under paragraph 100, the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised works and taking into account the need to ensure the safe and efficient operation of Cadent’s undertaking and Cadent must use its best endeavours to co-operate with the undertaker for that purpose. (2) For the avoidance of doubt whenever Cadent’s consent, agreement or approval is required in relation to plans, documents or other information submitted by the undertaker or the taking of action by the undertaker, Cadent’s consent must not be unreasonably withheld or delayed. Access 105 If in consequence of any agreement reached in accordance with paragraph 97(1) or the powers granted under this Order the access to any apparatus (including appropriate working areas required to reasonably and safely undertake necessary works by Cadent in respect of the apparatus) is materially obstructed, the undertaker must provide such alternative rights and means of access to such apparatus as will enable Cadent to maintain or use the apparatus no less effectively than was possible before such obstruction. Arbitration 106 Save for differences or disputes arising under paragraphs 98(2) and 98(4) any difference or dispute arising between the undertaker and Cadent under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and Cadent, be determined by arbitration in accordance with article 44 (arbitration). Notices 107 Notwithstanding article 46 (service of notices) any plans submitted to Cadent by the undertaker pursuant to paragraph 100(1) must be sent via email to Cadent Gas Limited Plant Protection at plantprotection@cadentgas.com copied by e-mail to landservices@cadentgas.com and sent to the General Counsel Department at Cadent’s registered office or such other address as Cadent may from time to time appoint instead for that purpose and notify to the undertaker in writing. PART 9 FOR THE PROTECTION OF THE LEAD LOCAL FLOOD AUTHORITY 108 The provisions of this Part have effect for the protection of the lead local flood authority unless otherwise agreed in writing between the undertaker and the lead local flood authority. 109 In this Part of this Schedule— “construction” includes execution, placing, altering, replacing, relaying and removal; and “construct” and “constructed” must be construed accordingly. “drainage authority” means in relation to an ordinary watercourse, the drainage board concerned within the meaning of section 23 (prohibition on obstructions etc. in watercourses) of the Land Drainage Act 1991; “drainage work” means any ordinary watercourse and includes any land that provides or is expected to provide flood storage capacity for any ordinary watercourse and any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage or flood defence; “evidence” includes hydraulic modelling, infiltration test results and geotechnical evaluations; “ordinary watercourse” has the meaning given in section 72 (Interpretation) of the Land Drainage Act 1991; “plans” includes sections, drawings, specifications and method statements; “specified work” means so much of any work or operation authorised by this Order as is in, on, under, over or within 9 metres of a drainage work or is otherwise likely to— affect any drainage work within the drainage authority area; affect the total volume or volumetric rate of flow of water in or flowing to or from any drainage work within the drainage authority area; affect the flow of water in any drainage work within the drainage authority area; and affect the conservation, distribution or use of water resources. 110 (1) Before beginning to construct any specified work, the undertaker must submit to the drainage authority plans of the specified work, evidence to support said plans and any such further particulars available to it as the drainage authority may within 28 days of the submission of the plans reasonably require (or submission of further particulars if required by the drainage authority). (2) Any such specified work must not be constructed except in accordance with such plans as may be approved in writing by the drainage authority or determined under paragraph 117. (3) Any approval of the drainage authority required under this paragraph— (a) must not be unreasonably withheld or delayed; (b) is deemed to have been given if it is neither given nor refused within 2 months of the submission of the plans for approval (or the submission of further particulars if applicable) or, in the case of a refusal, if it is not accompanied by a statement of the grounds of refusal; and (c) may be given subject to such reasonable requirements and conditions as the drainage authority may consider appropriate. (4) The drainage authority must use its reasonable endeavours to respond to the submission of any plans before the expiration of the period mentioned in sub-paragraph (3). 111 Without limiting paragraph 110, the requirements which the drainage authority may make under that paragraph include conditions requiring the undertaker at its own expense to construct such protective works, whether temporary or permanent, during the construction of the specified work (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary— (a) to safeguard any drainage work against damage; or (b) to secure that its efficiency for flood defence purposes is not impaired and that the risk of flooding is not otherwise increased, by reason of any specified work. 112 (1) Subject to sub-paragraph (2), any specified work, and all protective works required by the drainage authority under paragraph 111, must be constructed— (a) without unreasonable delay in accordance with the plans approved or deemed to have been approved or settled under this Part; and (b) to the reasonable satisfaction of the drainage authority, and an officer of the drainage authority is entitled to give such notice as may be reasonably required in the circumstances to watch and inspect the construction of such works. (2) The undertaker must give to the drainage authority— (a) not less than 14 days’ notice in writing of its intention to commence construction of any specified work; and (b) notice in writing of its completion not later than 7 days after the date on which it is brought into use. (3) If the drainage authority reasonably requires, the undertaker must construct all or part of the protective works so that they are in place before the construction of the specified work. (4) If any part of a specified work or any protective work required by the drainage authority is constructed otherwise than in accordance with the requirements of this Part, the drainage authority may by notice in writing require the undertaker at the undertaker’s expense to comply with the requirements of this Part or (if the undertaker so elects and the drainage authority in writing consents, such consent not to be unreasonably withheld or delayed) to remove, alter or pull down the work and, where removal is required, to restore the site to its former condition to such extent and within such limits as the drainage authority reasonably requires. (5) Subject to sub-paragraph (6), if within a reasonable period, being not less than 28 days from the date when a notice under sub-paragraph (4) is served on the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and subsequently to make reasonably expeditious progress towards their implementation, the drainage authority may execute the works specified in the notice, and any expenditure reasonably incurred by it in so doing is recoverable from the undertaker. (6) In the event of any dispute as to whether sub-paragraph (4) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the drainage authority must not except in emergency exercise the powers conferred by sub-paragraph (4) until the dispute has been finally resolved by agreement or determined under paragraph 117. 113 If by reason of the construction of any specified work or of the failure of any such work the efficiency of any drainage work for flood defence purposes is impaired, or the drainage work is otherwise damaged, the impairment or damage must be made good by the undertaker to the reasonable satisfaction of the drainage authority and, if the undertaker fails to do so, the drainage authority may make good the impairment or damage and recover from the undertaker the expense reasonably incurred by it in doing so. 114 The undertaker must compensate the drainage authority in respect of all costs, charges and expenses that the drainage authority may reasonably incur, have to pay or may sustain— (a) in the examination or approval of plans and evidence under this Part; (b) in inspecting the proposed site for and construction of any specified work or any protective works required by the drainage authority under this Part; and (c) in carrying out of any surveys or tests by the drainage authority that are reasonably required in connection with the construction of the specified work. 115 (1) Without limiting the other provisions of this Part, the undertaker must compensate the drainage authority in respect of all claims, demands, proceedings, costs, damages, expenses or loss that may be made or taken against, reasonably recovered from or incurred by the drainage authority by reason of— (a) any damage to any drainage work so as to impair its efficiency for the purposes of flood defence; (b) any flooding or increased flooding of any such land which is caused by, or results from, the construction of the specified work or any act or omission of the undertaker, its contractors, agents or employees whilst engaged upon the work. (2) The drainage authority must give to the undertaker reasonable notice of any such claim or demand, and no settlement or compromise may be made without the agreement of the undertaker which agreement must not be unreasonably withheld or delayed. (3) The drainage authority must use its reasonable endeavours to mitigate in whole or in part and to minimise any claims, demands, proceedings, costs, damages, expenses or loss to which this paragraph applies. If requested to do so by the undertaker, the drainage authority must provide an explanation of how the claim has been minimised. The undertaker is only liable under this paragraph for claims reasonably incurred by the drainage authority. 116 The fact that any work or thing has been executed or done by the undertaker in accordance with a plan approved or deemed to be approved by the drainage authority, or to its satisfaction, or in accordance with any directions or award of an arbitrator, does not relieve the undertaker from any liability under this Part. 117 Any dispute between the undertaker and the drainage authority under this Part, unless otherwise agreed, must be determined by arbitration under article 44 (arbitration).