The Peartree Hill Solar Farm Order 2026

SCHEDULE 11 PROTECTIVE PROVISIONS

Article 46 PART 1 FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWAGE UNDERTAKERS 1 For the protection of the utility undertakers referred to in this Part of this Schedule (save for any utility undertakers which are specifically protected by any other Part of this Schedule, which will take precedence) the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertaker concerned. 2 In this Part of this Schedule— “alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner no less efficient than previously; “apparatus” means— in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989), belonging to or maintained by that utility undertaker; in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter within the meaning of Part 1 of the Gas Act 1986 for the purposes of gas supply; in the case of a water undertaker, mains, pipes or other apparatus belonging to or maintained by that utility undertaker for the purposes of water supply; and in the case of a sewerage undertaker— any drain or works vested in the utility undertaker under the Water Industry Act 1991; and any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) (adoption of sewers and disposal of works) of that Act or an agreement to adopt made under section 104 (agreements to adopt sewer, drain or sewage disposal works, at a future date) of that Act, and includes a sludge main, disposal main (within the meaning of section 219 (general interpretation) of that Act) or sewer outfall and any inspection chambers, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus; “functions” includes powers and duties; “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; “plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed; “utility undertaker” means— any licence holder within the meaning of Part 1 of the Electricity Act 1989; a gas transporter within the meaning of Part 1 of the Gas Act 1986; a water undertaker within the meaning of the Water Industry Act 1991; and a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991; for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained. On street apparatus 3 This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act. Apparatus in stopped up public rights of way 4 Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 14 (temporary closure or restriction of streets and public rights of way), a utility undertaker is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street. Acquisition of land 5 Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement. Removal of apparatus 6 (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (7). (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus. (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed the utility undertaker must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed. (4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 44 (arbitration). (5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 44 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule. (6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that the undertaker desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker. (7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus. Facilities and rights for alternative apparatus 7 (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance of the utility undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 44 (arbitration). (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. Retained apparatus 8 (1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 6(2), the undertaker must submit to the utility undertaker in question a plan of the works to be executed. (2) Those works must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works. (3) Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan under sub-paragraph (1) is submitted to it. (4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 3, 6 and 7 apply as if the removal of the apparatus had been required by the undertaker under paragraph 6(2). (5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works unless otherwise agreed with the utility undertaker, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan. (6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances. Expenses and costs 9 (1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker all expenses reasonably incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 6(2). (2) There must be deducted from any sum payable under subparagraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule that value being calculated after removal. (3) If in accordance with the provisions of this Part of this Schedule— (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 44 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) must be reduced by the amount of that excess. (4) For the purposes of sub-paragraph (3)— (a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of an inspection chamber is to be treated as if it also had been agreed or had been so determined. (5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit. 10 (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraph 6(2), or by reason of any subsidence resulting from such development or works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must— (a) bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and (b) make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the undertaker, by reason or in consequence of any such damage or interruption. (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents. (3) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand. Cooperation 11 Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaker in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made. PART 2 FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS 12 For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator. 13 In this Part of this Schedule— “the 2003 Act” means the Communications Act 2003; “electronic communications apparatus” has the same meaning as in the electronic communications code; “the electronic communications code” has the same meaning as in section 106 (application of the electronic code) of the 2003 Act; “electronic communications code network” means— so much of an electronic communications network or infrastructure system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 (application of the electronic communications code) of the 2003 Act; and an electronic communications network which the Secretary of State is providing or proposing to provide; “electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 (application of the electronic communications code) of the 2003 Act; and “operator” means the operator of an electronic communications code network. 14 The exercise of the powers conferred by article 33 (statutory undertakers) is subject to Part 10 (undertaker’s works affecting electronic communications apparatus) of the electronic communications code. 15 (1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works— (a) any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or (b) there is any interruption in the supply of the service provided by an operator, the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption. (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents. (3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand. (4) Any difference arising between the undertaker and the operator under this Part of this Schedule must be referred to and settled by arbitration under article 44 (arbitration). (5) This Part of this Schedule does not apply to— (a) any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act; or (b) any damages, or any interruptions, caused by electro-magnetic interference arising from the construction or use of the authorised development. (6) Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made. PART 3 FOR THE PROTECTION OF THE DRAINAGE AUTHORITIES 16 The provisions of this Part have effect for the protection of a drainage authority unless otherwise agreed in writing between the undertaker and the drainage authority. 17 In this Part— “construction” includes execution, placing, altering, replacing, relaying and removal; and “construct” and “constructed” must be construed accordingly; “drainage authority” means in relation to an ordinary water course— the drainage board concerned within the meaning of section 23 (prohibition on obstructions etc. in watercourses) of the Land Drainage Act 1991; and in the case of any area for which there is no such drainage board, the lead local flood authority within the meaning of section (6) other definitions of the Flood and Water Management Act 2010; “drainage work” means any ordinary watercourse and includes any land that provides or is expected to provide flood storage capacity for any ordinary watercourse and any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage, or flood defence; “ordinary watercourse” has the meaning given by section 72 (interpretation) of the Land Drainage Act 1991; “plans” includes sections, drawings, specifications and method statements; and “specified work” means so much of any work or operation authorised by this Order as is in, on, under, over or within 8 metres (or 9 metres in the case of any drainage work under the control of the Beverley and North Holderness Internal Drainage Board) of a drainage work (measured from the bank top of the drainage work) or is otherwise likely to— affect the total volume or volumetric rate of flow of water in or flowing to or from any drainage work; or affect the conservation, distribution or use of water resources. 18 (1) Before beginning to construct any specified work, the undertaker must submit to the drainage authority plans of the specified work and such further particulars available to it as the drainage authority may within 28 days of the submission of the plans reasonably require. (2) The undertaker must not commence construction of the specified work until approval, unconditionally or conditionally, has been given as provided in this paragraph. (3) Any such specified work must not be constructed except in accordance with such plans as may be approved in writing by the drainage authority or determined under paragraph 24. (4) Any approval of the drainage authority required under this paragraph— (a) must not be unreasonably withheld; (b) is deemed to have been given if it is neither given nor refused within 2 months of the submission of the plans for approval (or submission of further particulars if required by the drainage authority under sub-paragraph (1)) and (c) may be given subject to such reasonable requirements as the drainage authority may make for the protection of any drainage work, for the prevention of flooding or pollution or discharge of its environmental function. (5) Any submission of plans for approval (or submission of further particulars if required by the drainage authority) under sub-paragraph (1) must include a statement that the provisions of sub-paragraph (3)(b) apply to that submission of plans for approval. (6) If a submission of plans for approval (or submission of further particulars if required by the drainage authority) under sub-paragraph (1) does not include the statement required under sub-paragraph (4), then the provisions of sub-paragraph (3)(b) will not apply to that submission of plans for approval. (7) Any refusal under this paragraph must be accompanied by a statement of the reasons for refusal. 19 Without limiting paragraph 18, the requirements which the drainage authority may make under that paragraph include conditions requiring the undertaker at its own expense to construct such protective works, whether temporary or permanent, during the construction of the specified work (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary— (a) to safeguard any drainage work against damage; or (b) to secure that its efficiency for flood defence purposes is not impaired and that the risk of flooding is not otherwise increased, by reason of any specified work. 20 (1) Subject to sub-paragraph (2), any specified work, and all protective works required by the drainage authority under paragraph 19, must be constructed— (a) without unreasonable delay in accordance with the plans approved or deemed to have been approved or settled under this Part; and (b) to the reasonable satisfaction of the drainage authority, and an officer of the drainage authority is entitled to watch and inspect the construction of such works. (2) The undertaker must give to the drainage authority— (a) not less than 14 days’ notice in writing of its intention to commence construction of any specified work; and (b) notice in writing of its completion not later than 7 days after the date of completion. (3) If the drainage authority reasonably requires, the undertaker must construct all or part of the protective works so that they are in place before the construction of the specified work. (4) If any part of a specified work or any protective work required by the drainage authority is constructed otherwise than in accordance with the requirements of this Part, the drainage authority may by notice in writing require the undertaker at the undertaker’s expense to comply with the requirements of this Part or (if the undertaker so elects and the drainage authority in writing consents, such consent not to be unreasonably withheld ) to remove, alter or pull down the work and, where removal is required, to restore the site to its former condition to such extent and within such limits as the drainage authority reasonably requires. (5) Subject to sub-paragraph (6), if within a reasonable period, being not less than 28 days from the date when a notice under sub-paragraph (4) is served on the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and subsequently to make reasonably expeditious progress towards their implementation, the drainage authority may execute the works specified in the notice, and any expenditure reasonably incurred by it in so doing is recoverable from the undertaker. (6) In the event of any dispute as to whether sub-paragraph (4) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the drainage authority must not except in emergency exercise the powers conferred by sub-paragraph (4) until the dispute has been finally determined under paragraph 25. 21 If by reason of the construction of any specified work or of the failure of any such work the efficiency of any drainage work for flood defence purposes is impaired, or the drainage work is otherwise damaged, the impairment or damage must be made good by the undertaker as soon as reasonably practicable to the reasonable satisfaction of the drainage authority and, if the undertaker fails to do so, the drainage authority may make good the impairment or damage and recover from the undertaker the expense reasonably incurred by it in doing so. 22 The undertaker must make reasonable compensation to the drainage authority in respect of all reasonable costs, charges and expenses that the drainage authority may reasonably incur, have to pay or may sustain— (a) in the examination or approval of plans under this Part; (b) in inspecting the construction of any specified work or any protective works required by the drainage authority under this Part; and (c) in carrying out of any surveys or tests by the drainage authority that are reasonably required in connection with the construction of the specified work. 23 (1) Without limiting the other provisions of this Part, the undertaker must make reasonable compensation to the drainage authority in respect of all reasonable claims, demands, proceedings, costs, damages, expenses or loss that may be made or taken against, reasonably recovered from or incurred by, the drainage authority by reason of— (a) any damage to any drainage work so as to impair its efficiency for the purposes of flood defence; or (b) any flooding or increased flooding of any such land, that is caused by the construction of any specified work or any act or omission of the undertaker, its contractors, agents or employees whilst engaged on the work. (2) The drainage authority must give to the undertaker reasonable notice of any such claim or demand, and no settlement or compromise may be made without the agreement of the undertaker (such agreement not to be unreasonably withheld ). (3) The drainage authority must use its reasonable endeavours to mitigate in whole or in part and to minimise any claims, demands, proceedings, costs, damages, expenses or loss to which this paragraph applies. (4) If requested to do so by the undertaker, the drainage authority must provide an explanation of how the claim has been minimised. (5) The undertaker is only liable under this paragraph for claims reasonably incurred by the drainage authority. (6) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage to the extent that it is attributable to the act, neglect or default of the drainage authority or the breach of a statutory duty of the drainage authority, its officers, servants, contractors or agents. 24 The fact that any work or thing has been executed or done by the undertaker in accordance with a plan approved or deemed to be approved by the drainage authority, or to its satisfaction, or in accordance with any directions or award of an arbitrator, does not relieve the undertaker from any liability under this Part. 25 Any dispute between the undertaker and the drainage authority under this Part, unless otherwise agreed, must be determined by arbitration under article 44 (arbitration). PART 4 FOR THE PROTECTION OF THE ENVIRONMENT AGENCY 26 (1) The following provisions apply for the protection of the Agency unless otherwise agreed in writing between the undertaker and the Agency. (2) In this Part of this Schedule— “Agency” means the Environment Agency; “construction” includes execution, placing, altering, replacing, relaying and removal and excavation and “construct” and “constructed” is construed accordingly; “drainage work” means any main river and includes any land which provides or is expected to provide flood storage capacity for any main river and any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage, flood defence or tidal monitoring; “emergency” means an occurrence which presents a material risk— serious flooding; serious detrimental impact on drainage; or serious harm to the environment; “fishery” means any waters containing fish and fish in, or migrating to or from, such waters and the spawn, spawning ground, habitat or food of such fish; “main river” has the same meaning given in section 113 of the Water Resources Act 1991; “non-tidal main river” has the meaning given in paragraph 2(1) of Part 1 of Schedule 25 to the Environmental Permitting (England and Wales) Regulations 2016; “plans” includes plans, sections, elevations, drawings, specifications, programmes, proposals, calculations, method statements and descriptions; “remote defence” means any berm, wall or embankment that is constructed for the purposes of preventing or alleviating flooding from, or in connection with, any main river; “sea defence” means any bank, wall, embankment (any berm, counterwall or cross-wall connected to any such bank, wall or embankment), barrier, tidal sluice and other defence, whether natural or artificial, against the inundation of land by sea water or tidal water, including natural or artificial high ground which forms part of or makes a contribution to the efficiency of the defences of the Agency’s area against flooding, but excludes any sea defence works which are for the time being maintained by a coast protection authority under the provisions of the Coast Protection Act 1949 or by any local authority or any navigation, harbour or conservancy authority; “specified work” means so much of any work or operation authorised by this Order as is in, on, under, over or within— 16 metres of the base of a sea defence which is likely to— endanger the stability of, cause damage or reduce the effectiveness of that sea defence, or interfere with the Agency’s access to or along that sea defence or the Agency’s ability to undertake works to ensure the efficacy of that sea defence; 8 metres of the base of a remote defence which is likely to— endanger the stability of, cause damage or reduce the effectiveness of that remote defence, or interfere with the Agency’s access to or along that remote defence; 16 metres of a drainage work involving a tidal main river; 8 metres of a drainage work involving a non-tidal river— or any distance of a drainage work and is otherwise likely to— affect any drainage work or the volumetric rate of flow of water in or flowing to or from any drainage work; affect the flow, purity or quality of water in any main river or other surface waters; cause obstruction to the free passage of fish or damage to any fishery; affect the conservation, distribution or use of water resources; or affect the conservation value of the main river and habitats in its immediate vicinity; or which involves— an activity that includes dredging, raising or taking of any sand, silt, ballast, clay, gravel or other materials from or off the bed or banks of a drainage work (or causing such materials to be dredged, raised or taken), including hydrodynamic dredging or desilting; and any quarrying or excavation within 16 metres of a drainage work which is likely to cause damage to or endanger the stability of the banks or structure of that drainage work; and “tidal main river” has the meaning given in paragraph 2(1) of Part 1 of Schedule 25 to the Environmental Permitting (England and Wales) Regulations 2016. Submission and approval of plans 27 (1) Before beginning to construct any specified work, the undertaker must submit to the Agency plans of the specified work and such further particulars available to it as the Agency may within 28 days of the receipt of the plans reasonably request. (2) Any such specified work must not be constructed except in accordance with such plans as may be approved in writing by the Agency, or determined under paragraph 36. (3) Any approval of the Agency required under this paragraph— (a) must not be unreasonably withheld or delayed; (b) subject to sub-paragraph (5), is deemed to have been refused if it is neither given nor refused within 2 months of the submission of the plans such later date as is agreed between the Agency and the undertaker if further particulars have been requested in accordance with sub-paragraph (1) the period between the making of this request and the provision of further particulars in response to it must not be taken into account in the calculation of the 2 months for the purposes of this sub-paragraph; and (c) may be given subject to such reasonable requirements as the Agency may have for the protection of any drainage work or the fishery or for the protection of water resources, or for the prevention of flooding or pollution or for nature conservation or the prevention of environmental harm in the discharge of its environmental duties. (4) The Agency must use its reasonable endeavours to respond to the submission of any plans before the expiration of the period mentioned in sub-paragraph (3)(b). (5) In the case of a refusal, the Agency must provide reasons for the grounds of that refusal. Construction of protective works 28 Without limiting paragraph 27 the requirements which the Agency may have under that paragraph include conditions requiring the undertaker, at its own expense, to construct such protective works, whether temporary or permanent, before or during the construction of the specified works (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary— (a) to safeguard any drainage work against damage; or (b) to secure that its efficiency for flood defence purposes is not impaired and that the risk of flooding is not otherwise increased, by reason of any specified work. Timing of works and service of notices 29 (1) Subject to sub-paragraph (2), any specified work, and all protective works required by the Agency under paragraph 28, must be constructed— (a) without unreasonable delay in accordance with the plans approved under this Part of this Schedule; and (b) to the reasonable satisfaction of the Agency, and the Agency is entitled by its officer to watch and inspect the construction of such works. (2) The undertaker must give to the Agency not less than 14 days’ notice in writing of its intention to commence construction of any specified work and notice in writing of its completion not later than 7 days after the date on which it is completed. (3) If the Agency reasonably requires, the undertaker must construct all or part of the protective works so that they are in place prior to the construction of any specified work to which the protective works relate. Works not in accordance with this Schedule 30 (1) If there is any failure by the undertaker to obtain consent or comply with conditions imposed by the Agency in accordance with these protective provisions and where the Agency acting reasonably considers it necessary to avoid any of the risks specified in sub-paragraph (2), the Agency may serve written notice requiring the undertaker to cease all or part of the specified works as may be specified within the notice within such reasonable period as specified in the notice, and the undertaker must cease constructing the specified works or part thereof until such time as it has obtained the consent or complied with the condition specified within the notice served. (2) The risks specified in sub-paragraph (1) are— (a) risk of flooding; (b) risk of harm to the environment; (c) risk of detrimental impact on drainage; (d) damage to the fishery. 31 (1) If any part of a specified work or any protective work required by the Agency is constructed otherwise than in accordance with the requirements of this Part of this Schedule, the Agency may by notice in writing require the undertaker at the undertaker’s own expense to comply with the requirements of this Part of this Schedule or (if the undertaker so elects and the Agency in writing consents, such consent not to be unreasonably withheld or delayed) to remove, alter or pull down the work and, where removal is required, to restore the site to its former condition to such extent and within such limits as the Agency reasonably requires. (2) Subject to sub-paragraph (3) if, within a reasonable period, being not less than 28 days beginning with the date when a notice under sub-paragraph (1) is served upon the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, the Agency may execute the works specified in the notice and any reasonable expenditure incurred by the Agency in so doing is recoverable from the undertaker. (3) In the event of any dispute as to whether sub-paragraph (1) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the Agency must not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (2) until the dispute has been finally determined in accordance with paragraph 37. Maintenance of works 32 (1) Subject to sub-paragraph (5) the undertaker must from the commencement of the construction of the specified works maintain in good repair and condition and free from obstruction any drainage work which is situated within the Order limits and on land held by the undertaker for the purposes of or in connection with the specified works, whether or not the drainage work is constructed under the powers conferred by this Order or is already in existence. (2) If any such drainage work which the undertaker is liable to maintain is not maintained to the reasonable satisfaction of the Agency, the Agency may by notice in writing require the undertaker to repair and restore the work, or any part of such work, or (if the undertaker so elects and the Agency in writing consents, such consent not to be unreasonably withheld or delayed), to remove the work and restore the site to its former condition, to such extent and within such limits as the Agency reasonably requires. (3) Subject to sub-paragraph (4) if, within a reasonable period, being not less than 28 days beginning with the date on which a notice in respect of any drainage work is served under sub-paragraph (2) on the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, the Agency may do what is necessary for such compliance and any reasonable expenditure incurred by the Agency in so doing is recoverable from the undertaker. (4) In the event of any dispute as to the reasonableness of any requirement of a notice served under sub-paragraph (2), the Agency must not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (3) until the dispute has been finally determined in accordance with paragraph 37. (5) This paragraph does not apply to— (a) drainage works which are vested in the Agency, or which the Agency or another person is liable to maintain and is not proscribed by the powers of the Order from doing so; and (b) any obstruction of a drainage work expressly authorised in the approval of specified works plans and carried out in accordance with the provisions of this Part of this Schedule provided that any obstruction is removed as soon as reasonably practicable. Remediating impaired drainage work 33 If by reason of the construction of any specified work or of the failure of any such work, the efficiency of any drainage work for flood defence purposes is impaired, or that drainage work is otherwise damaged, such impairment or damage must be made good by the undertaker to the reasonable satisfaction of the Agency and if the undertaker fails to do so, the Agency may make good the impairment or damage and recover any expenditure incurred by the Agency in so doing from the undertaker. Agency access 34 If by reason of the construction of any specified work or the failure of any such work, the Agency’s access to flood defences or equipment maintained for flood defence purposes is materially obstructed, the undertaker must notify the Agency as soon as reasonably practicable and provide suitable alternative means of access that will allow the Agency to maintain the flood defence or use the equipment no less effectively than was possible before the obstruction occurred and such alternative access must be made available or as soon as reasonably practicable after the undertaker becomes aware of such obstruction, except in the case of an emergency in which case the undertaker must provide such alternative means of access on demand unless to do so would cause danger to persons or property. Free passage of fish 35 (1) The undertaker must take all such measures as may be reasonably practicable to prevent any interruption of the free passage of fish in the fishery during the construction of any specified work. (2) If by reason of— (a) the construction of any specified work; or (b) the failure of any such work, damage to the fishery is caused, or the Agency has reason to expect that such damage may be caused, the Agency may serve notice on the undertaker requiring it to take such steps as may be reasonably practicable to make good the damage and provide a reasonable period in which those steps must be taken, or, as the case may be, to protect the fishery against such damage. (3) If within such time as notified in sub-paragraph (2), the undertaker fails to take such steps as are described in sub-paragraph (2), the Agency may take those steps and any expenditure incurred by the Agency in so doing is recoverable from the undertaker. (4) In any case where immediate action by the Agency is reasonably required in order to secure that the risk of damage to the fishery is avoided or reduced, the Agency may take such steps as are reasonable for the purpose, and may recover from the undertaker any expenditure incurred in so doing provided that notice specifying those steps is served on the undertaker as soon as reasonably practicable after the Agency has taken, or commenced to take, the steps specified in the notice. Indemnity 36 (1) The undertaker indemnifies the Agency in respect of all costs, charges and expenses which the Agency may reasonably incur— (a) in the examination or approval of plans under this Part of this Schedule; (b) in the inspection of the construction of the specified works or any protective works required by the Agency under this Part of this Schedule; and (c) in the carrying out of any surveys or tests by the Agency which are reasonably required in connection with the construction of the specified works. (2) The undertaker is responsible for and indemnifies the Agency against all costs and losses, liabilities, claims and demands not otherwise provided for in this Schedule which may be reasonably incurred or suffered by the Agency by reason of, or arising out of— (a) the construction, operation or maintenance of any specified works comprised within the authorised development or the failure of any such works comprised within them; or (b) any act or omission of the undertaker, its employees, contractors or agents or others whilst engaged upon the construction, operation or maintenance of the authorised development or dealing with any failure of the authorised development. (3) For the avoidance of doubt, in sub-paragraphs (1) and (2)— (a) “costs” includes— (i) expenses and charges; (ii) staff costs and overheads; and (iii) legal costs; (b) “losses” includes physical damage; (c) “claims” and “demands” include as applicable— (i) costs (within the meaning of this sub-paragraph incurred in connection with any claim or demand; and (ii) any interest element of sums claimed or demanded; (d) “liabilities” includes— (i) contractual liabilities; (ii) tortious liabilities (including liabilities for negligence or nuisance); (iii) liabilities to pay statutory compensation or for breach of statutory duty; and (iv) liabilities to pay statutory penalties imposed on the basis of strict liability (but does not include liabilities to pay other statutory penalties). (4) The Agency must give to the undertaker reasonable notice of any such claim or demand and must not settle or compromise a claim without the agreement of the undertaker and that agreement must not be unreasonably withheld or delayed. (5) The Agency must, at all times take reasonable steps to prevent and mitigate any such claims, demands, proceedings, costs, damages, expenses or loss. (6) The fact that any work or thing has been executed or done by the undertaker in accordance with a plan approved by the Agency, or to its satisfaction, or in accordance with any directions or award of an arbitrator, must not relieve the undertaker from any liability under the provisions of this Part of this Schedule. (7) Nothing in this paragraph imposes any liability on the undertaker with respect to any costs, charges, expenses, damages, claims, demands or losses to the extent that they are attributable to the neglect or default of the Agency, its officers, servants, contractors or agents. Disputes 37 Any dispute arising between the undertaker and the Agency under this Part of this Schedule must, if the parties agree, be determined by arbitration under article 44 (arbitration), but failing agreement be determined by the Secretary of State for Environment, Food and Rural Affairs or its successor and the Secretary of State for the department of Energy Security and Net Zero or its successor acting jointly on a reference to them by the undertaker or the Agency, after notice in writing by one to the other. PART 5 FOR THE PROTECTION OF NATIONAL GAS TRANSMISSION PLC AS GAS UNDERTAKER Application 38 (1) For the protection of National Gas as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and National Gas. (2) Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the undertaker and National Gas, where the benefit of this Order is transferred or granted to another person under article 8 (consent to transfer benefit of Order)— (a) any agreement of the type mentioned in subparagraph (1) has effect as if it had been made between National Gas and the transferee or grantee (as the case may be); and (b) written notice of the transfer or grant must be given to National Gas on or before the date of that transfer or grant. (3) Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to National Gas (but without prejudice to paragraph 48(3)b). Interpretation 39 (1) In this Part of this Schedule— “1991 Act” means the New Roads and Street Works Act 1991; “acceptable credit provider” means a bank or financial institution with a credit rating that is not lower than “A-” if the rating is assigned by Standard & Poor’s Ratings Group or Fitch Ratings; and “A3” if the rating is assigned by Moody’s Investors Services Inc.; “acceptable insurance” means general third party liability insurance effected and maintained by the undertaker with a combined property damage and bodily injury limit of indemnity of not less than £50,000,000.00 (fifty million pounds) per occurrence or series of occurrences arising out of one event. Such insurance shall be maintained (a) during the construction period of the authorised works; and (b) after the construction period of the authorised works in respect of any use and maintenance of the authorised works by or on behalf of the undertaker which constitute specified works and arranged with an insurer whose security/credit rating meets the same requirements as an “acceptable credit provider”, such insurance shall include (without limitation)— a waiver of subrogation and an indemnity to principal clause in favour of National Gas; and pollution liability for third party property damage and third party bodily damage arising from any pollution/contamination event with a (sub)limit of indemnity of not less than £10,000,000.00 (ten million pounds) per occurrence or series of occurrences arising out of one event or £20,000,000.00 (twenty million pounds) in aggregate; “acceptable security” means either— a parent company guarantee from a parent company in favour of National Gas to cover the undertaker’s liability to National Gas to a total liability cap of £50,000,000.00 (fifty million pounds) (in a form reasonably satisfactory to National Gas and where required by National Gas, accompanied with a legal opinion confirming the due capacity and authorisation of the parent company to enter into and be bound by the terms of such guarantee); or a bank bond or letter of credit from an acceptable credit provider in favour of National Gas to cover the undertaker’s liability to National Gas for an amount of not less than £10,000,000.00 (ten million pounds) per asset per event up to a total liability cap of £50,000,000.00 (fifty million pounds) (in a form reasonably satisfactory to National Gas); “alternative apparatus” means appropriate alternative apparatus to the satisfaction of National Gas to enable National Gas to fulfil its statutory functions in a manner no less efficient than previously; “apparatus” means any mains, pipes or other apparatus belonging to or maintained by National Gas for the purposes of gas supply, together with any replacement apparatus and such other apparatus constructed pursuant to the Order that becomes operational apparatus of National Gas for the purposes of transmission, distribution and/or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus; “authorised works” has the same meaning as is given to the term “authorised development” in article 2(1) (interpretation) of this Order and includes any associated development authorised by the Order and for the purposes of this Part of this Schedule includes the use and maintenance of the authorised works and construction of any works authorised by this Schedule; “commence” and “commencement” has the same meaning as in article2(1) (interpretation) of this Order save that for the purposes of this Part of this Schedule shall include any below ground surveys, monitoring, ground work operations or the receipt and erection of construction plant and equipment; “deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, enactments and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule; “functions” includes powers and duties; “ground mitigation scheme” means a scheme approved by National Gas (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event; “ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, shall require the undertaker to submit for National Gas’s approval a ground mitigation scheme; “ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme; “in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land; “maintain” and “maintenance” shall include the ability and right to do any of the following in relation to any apparatus or alternative apparatus of National Gas, including to construct, use, repair, alter, inspect, renew or remove the apparatus; “National Gas” means National Gas Transmission plc (Company Number 02006000) whose registered office is at National Grid House, Warwick Technology Park, Gallows Hill, Warwick, CV34 6DA or any successor as a gas transporter within the meaning of Part 1 of the Gas Act 1986; “Network Code” means the network code prepared by National Gas pursuant to Standard Special Condition A11(3) of its Gas Transporter’s Licence, which incorporates the Uniform Network Code, as defined in Standard Special Condition A11(6) of National Gas’s Gas Transporters Licence, as both documents are amended from time to time; “Network Code Claims” means any claim made against National Gas by any person or loss suffered by National Gas under the Network Code arising out of or in connection with any failure by National Gas to make gas available for off take at, or a failure to accept gas tendered for delivery from, any entry point to or exit point from the gas national transmission system as a result of the authorised works or any costs and/or expenses incurred by National Gas as a result of or in connection with, it taking action (including purchase or buy back of capacity) for the purpose of managing constraint or potential constraint on the gas national transmission system which may arise as a result of the authorised works “plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed; “parent company” means a parent company of the undertaker acceptable to and which shall have been approved by National Gas acting reasonably; “specified works” means any of the authorised works or activities undertaken in association with the authorised works which— will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph 7(2) or otherwise; and/or may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under paragraph 44(2) or otherwise; and/or includes any of the activities that are referred to in paragraph 8 of T/SP/SSW/22 (National Gas’s policies for safe working in proximity to gas apparatus “Specification for safe working in the vicinity of National Gas, High pressure Gas pipelines and associated installation requirements for third parties”; and “undertaker” means the undertaker as defined in article 2(1) of this Order. On street apparatus 40 Except for paragraphs 41 (apparatus of National Gas in temporarily closed or restricted streets), 9 (retained apparatus: protection of gas undertaker), 47 (expenses) and 48 (indemnity) of this Schedule which will apply in respect of the exercise of all or any powers under the Order affecting the rights and apparatus of National Gas, the other provisions of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and National Gas are regulated by the provisions of Part 3 of the 1991 Act. Apparatus of National Gas in temporarily closed or restricted streets 41 Where any street is temporarily closed or restricted under the powers of article 15 (Temporary closure or restriction of streets and public rights of way) , National Gas is at liberty at all times to take all necessary access across any such temporarily closed or restricted street and to execute and do all such works and things in, upon or under any such streets may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the temporary closure or restriction was in that street. Protective works to buildings 42 The undertaker, in the case of the powers conferred by article 20 (protective work to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus without the written consent of National Gas. Acquisition of land 43 (1) Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference to the Order, the undertaker may not (a) appropriate or acquire or take temporary possession of any land or apparatus or ((b) appropriate, acquire, extinguish, interfere with or override any easement, other interest or right and/or apparatus of National Gas otherwise than by agreement. (2) As a condition of an agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised works (or in such other timeframe as may be agreed between National Gas and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of National Gas or affect the provisions of any enactment or agreement regulating the relations between National Gas and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as National Gas reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between National Gas and the undertaker acting reasonably and which must be no less favourable on the whole to National Gas unless otherwise agreed by National Gas, and it will be the responsibility of the undertaker to procure and/or secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works. (3) Save where otherwise agreed in writing between National Gas and the undertaker the undertaker and National Gas agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation and/or removal of apparatus/including but not limited to the payment of costs and expenses relating to such relocation and/or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by National Gas and/or other enactments relied upon by National Gas as of right or other use in relation to the apparatus, then the provisions in this Schedule shall prevail. (4) Any agreement or consent granted by National Gas under paragraph 46 (Retained apparatus: protection of gas undertaker) or any other paragraph of this Part of this Schedule, shall not be taken to constitute agreement under sub-paragraph (1). Removal of apparatus 44 (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in or possesses temporarily any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of National Gas to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of National Gas in accordance with sub-paragraphs (2) to (5). (2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to National Gas advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order National Gas reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), secure any necessary consents for the alternative apparatus and afford to National Gas to its satisfaction (taking into account paragraph 45(1) below) the necessary facilities and rights— (a) for the construction of alternative apparatus in other land of or land secured by the undertaker; and (b) subsequently for the maintenance of that apparatus. (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, National Gas may in its sole discretion, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances to assist the undertaker to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation must not extend to the requirement for National Gas to use its compulsory purchase powers to this end unless it elects to so do. (4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between National Gas and the undertaker. (5) National Gas must, after the alternative apparatus to be provided or constructed has been agreed, and subject to a written diversion agreement having been entered into between the parties and the grant to National Gas of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule. Facilities and rights for alternative apparatus 45 (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for National Gas facilities and rights in land for the construction, use, maintenance and protection of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and National Gas and must be no less favourable on the whole to National Gas than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by National Gas. (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to National Gas than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject the matter may be referred to arbitration in accordance with paragraph 52 (Arbitration) of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to National Gas as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. Retained apparatus: protection of gas undertaker 46 (1) Not less than 56 days before the commencement of any specified works the undertaker must submit to National Gas a plan and, if reasonably required by National Gas, a ground monitoring scheme in respect of those works. (2) In relation to specified works the plan to be submitted to National Gas under sub-paragraph (1) must include a method statement and describe— (a) the exact position of the works; (b) the level at which these are proposed to be constructed or renewed; (c) the manner of their construction or renewal including details of excavation, positioning of plant etc.; (d) the position of all apparatus; (e) by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus; and (f) any intended maintenance regimes. (3) The undertaker must not commence any works to which sub-paragraphs (1) and (2) apply until National Gas has given written approval of the plan so submitted. (4) Any approval of National Gas required under sub-paragraph (3)— (a) may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs (5) or (6); and (b) must not be unreasonably withheld. (5) In relation to any works to which sub-paragraphs (1) and/or (2) apply, National Gas may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage for the provision of protective works or for the purpose of providing or securing proper and convenient means of access to any apparatus. (6) Works executed under sub-paragraphs (1) or (2) must be executed in accordance with the plan, submitted under sub-paragraph (1) or as relevant sub paragraph (5), as approved or as amended from time to time by agreement between the undertaker and National Gas and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (5) or (7) by National Gas for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Gas will be entitled to watch and inspect the execution of those works. (7) Where National Gas requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to National Gas’ satisfaction prior to the commencement of any specified works for which protective works are required and National Gas must give notice of its requirement for such works within 42 days of the date of submission of a plan pursuant to this paragraph (except in an emergency). (8) If National Gas in accordance with sub-paragraphs (5) or (7) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 3 and 6 to 8 apply as if the removal of the apparatus had been required by the undertaker under paragraph 44(2). (9) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the specified works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph will apply to and in respect of the new plan. (10) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to National Gas notice as soon as is reasonably practicable and a plan of those works and must comply with sub-paragraphs (6), (7) and (8) insofar as is reasonably practicable in the circumstances and comply with sub-paragraph (11) at all times; (11) At all times when carrying out any works authorised under the Order, the undertaker must comply with National Gas’s policies for safe working in proximity to gas apparatus “Specification for safe working in the vicinity of National Gas, High pressure Gas pipelines and associated installation requirements for third parties T/SP/SSW22” and HSE’s “HS(~G)47 Avoiding Danger from underground services”. (12) As soon as reasonably practicable after any ground subsidence event attributable to the authorised development the undertaker shall implement an appropriate ground mitigation scheme save that National Gas retains the right to carry out any further necessary protective works for the safeguarding of its apparatus and can recover any such costs in line with paragraph 47 (Expenses). Expenses 47 (1) Save where otherwise agreed in writing between National Gas and the undertaker and subject to the following provisions of this paragraph, the undertaker must pay to National Gas within 30 days of receipt of an itemised invoice or claim from National Gas all charges, costs and expenses reasonably anticipated within the following three months or reasonably and properly incurred by National Gas in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised works including without limitation— (a) any costs reasonably incurred by or compensation properly paid by National Gas in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs incurred by National Gas as a consequence of National Gas; (i) using its own compulsory purchase powers to acquire any necessary rights under paragraph 44(3); or (ii) exercising any compulsory purchase powers in the Order transferred to or benefitting National Gas; (b) in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus, where no written diversion agreement is otherwise in place; (c) the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus; (d) the approval of plans; (e) the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works; (f) the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule. (2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal. (3) If in accordance with the provisions of this Part of this Schedule— (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 52 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Gas by virtue of sub-paragraph (1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker. (4) For the purposes of sub-paragraph (3)— (a) an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined. (5) Any amount which apart from this sub-paragraph would be payable to National Gas in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Gas any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit. Indemnity 48 (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Part of this Schedule or in consequence of the construction, use maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised works) or property of National Gas, or there is any interruption in any service provided, or in the supply of any goods or energy, by National Gas, or National Gas becomes liable to pay any amount to any third party, the undertaker will— (a) bear and pay on demand accompanied by an invoice or claim from National Gas the cost reasonably and properly incurred by National Gas in making good such damage or restoring the supply; and (b) indemnify National Gas for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from National Gas, by reason or in consequence of any such damage or interruption or National Gas becoming liable to any third party and including Network Code Claims other than arising from any default of National Gas. (2) The fact that any act or thing may have been done by National Gas on behalf of the undertaker or in accordance with a plan approved by National Gas or in accordance with any requirement of National Gas or under its supervision will not (unless sub-paragraph (3) applies), excuse the undertaker from liability under the provisions of this sub-paragraph (1) unless National Gas fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan. (3) Nothing in sub-paragraph (1) shall impose any liability on the undertaker in respect of— (a) any damage or interruption to the extent that it is attributable to the neglect or default of National Gas, its officers, servants, contractors or agents; (b) any authorised works and/or any other works authorised by this Part of this Schedule carried out by National Gas as an assignee, transferee or lessee of the undertaker with the benefit of the Order pursuant to section 156 of the Planning Act 2008 or article 8 (consent to transfer benefit of Order) subject to the proviso that once such works become apparatus (“new apparatus”), any authorised works yet to be executed and not falling within this sub-paragraph 3(b) will be subject to the full terms of this Part of this Schedule including this paragraph 48; and/or (c) any indirect or consequential loss of any third party (including but not limited to loss of use, revenue, profit, contract, production, increased cost of working or business interruption) arising from any such damage or interruption, which is not reasonably foreseeable; (4) National Gas must give the undertaker reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations. (5) National Gas must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds. (6) National Gas must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within National Gas’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of National Gas’s control and if reasonably requested to do so by the undertaker National Gas must provide an explanation of how the claim has been minimised, where relevant. (7) The undertaker must not commence construction (and not permit the commencement of such construction) of the authorised works on any land owned by National Gas or in respect of which National Gas has an easement or wayleave for its apparatus or any other interest or to carry out any works within 15 metres of National Gas’s apparatus until the following conditions are satisfied— (a) unless and until National Gas is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has first provided the acceptable security (and provided evidence that it shall maintain such acceptable security for the construction period of the authorised works from the proposed date of commencement of construction of the authorised works) and National Gas has confirmed the same to the undertaker in writing; and (b) unless and until National Gas is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has procured acceptable insurance (and provided evidence to National Gas that it shall maintain such acceptable insurance for the construction period of the authorised works from the proposed date of commencement of construction of the authorised works) and National Gas has confirmed the same in writing to the undertaker. (8) In the event that the undertaker fails to comply with sub-paragraph (7) of this paragraph, nothing in this Part of this Schedule shall prevent National Gas from seeking injunctive relief (or any other equitable remedy) in any court of competent jurisdiction. Enactments and agreements 49 Save to the extent provided for to the contrary elsewhere in this Part of this Schedule or by agreement in writing between National Gas and the undertaker, nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and National Gas in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made. Co-operation 50 (1) Where in consequence of the proposed construction of any part of the authorised works, the undertaker or National Gas requires the removal of apparatus under paragraph 44(2) or National Gas makes requirements for the protection or alteration of apparatus under paragraph 46 (Retained apparatus: protection of gas undertaker) the undertaker shall use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised works and taking into account the need to ensure the safe and efficient operation of National Gas’s undertaking and National Gas shall use its best endeavours to co-operate with the undertaker for that purpose. (2) For the avoidance of doubt whenever National Gas’s consent, agreement or approval is required in relation to plans, documents or other information submitted by the undertaker or the taking of action by the undertaker, it must not be unreasonably withheld or delayed. Access 51 If in consequence of the agreement reached in accordance with paragraph 43(1) or the powers granted under this Order the access to any apparatus is materially obstructed, the undertaker must provide such alternative means of access to such apparatus as will enable National Gas to maintain or use the apparatus no less effectively than was possible before such obstruction. Arbitration 52 Save for differences or disputes arising under paragraph 44(2), 44(4) 45(1) and 46 any difference or dispute arising between the undertaker and National Gas under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and National Gas, be determined by arbitration in accordance with article 49 (arbitration). Notices 53 Notwithstanding article 43 (service of notices), any plans submitted to National Gas by the undertaker pursuant to paragraph 9 (Retained apparatus: protection of gas undertaker) must be submitted using the LSBUD system (https://lsbud.co.uk/) or such other address as National Gas may from time to time appoint instead for that purpose and notify to the undertaker in writing. PART 6 FOR THE PROTECTION OF NATIONAL GAS ELECTRICITY TRANSMISSION PLC AS ELECTRICITY UNDERTAKER Application 54 (1) For the protection of National Grid Electricity Transmission Plc as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and National Grid Electricity Transmission Plc. (2) Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the undertaker and National Grid Electricity Transmission Plc, where the benefit of this Order is transferred or granted to another person under article 8 (consent to transfer benefit of Order)— (a) any agreement of the type mentioned in subparagraph (1) has effect as if it had been made between National Grid Electricity Transmission Plc and the transferee or grantee (as the case may be); and (b) written notice of the transfer or grant must be given to National Grid Electricity Transmission Plc on or before the date of that transfer or grant. (3) Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to National Grid Electricity Transmission Plc (but without prejudice to 66(3)(b)). Interpretation 55 In this Part of this Schedule— “acceptable credit provider” means a bank or financial institution with a credit rating that is not lower than “A-” if the rating is assigned by Standard & Poor’s Ratings Group or Fitch Ratings; and “A3” if the rating is assigned by Moody’s Investors Services Inc.; “acceptable insurance” means general third party liability insurance effected and maintained by the undertaker with a combined property damage and bodily injury limit of indemnity of not less than £50,000,000.00 (fifty million pounds) per occurrence or series of occurrences arising out of one event. Such insurance shall be maintained (a) during the construction period of the authorised works; and (b) after the construction period of the authorised works in respect of any use and maintenance of the authorised works by or on behalf of the undertaker which constitute specified works and arranged with an insurer whose security/credit rating meets the same requirements as an “acceptable credit provider”, such insurance shall include (without limitation)— a waiver of subrogation and an indemnity to principal clause in favour of National Grid Electricity Transmission Plc; and/or pollution liability for third party property damage and third-party bodily damage arising from any pollution/contamination event with a (sub)limit of indemnity of not less than £10,000,000.00 (ten million pounds) per occurrence or series of occurrences arising out of one event or £20,000,000.00 (twenty million pounds) in aggregate; “acceptable security” means either— a parent company guarantee from a parent company in favour of National Grid Electricity Transmission Plc to cover the undertaker’s liability to National Grid Electricity Transmission Plc to a total liability cap of £50,000,000.00 (fifty million pounds) (in a form reasonably satisfactory to National Grid Electricity Transmission Plc and where required by National Grid Electricity Transmission Plc, accompanied with a legal opinion confirming the due capacity and authorisation of the parent company to enter into and be bound by the terms of such guarantee); or a bank bond or letter of credit from an acceptable credit provider in favour of National Grid Electricity Transmission Plc to cover the undertaker’s liability to National Grid Electricity Transmission Plc for an amount of not less than £10,000,000.00 (ten million pounds) per asset per event up to a total liability cap of £50,000,000.00 (fifty million pounds) (in a form reasonably satisfactory to National Grid Electricity Transmission Plc); “alternative apparatus” means appropriate alternative apparatus to the satisfaction of National Grid Electricity Transmission Plc to enable National Grid Electricity Transmission Plc to fulfil its statutory functions in a manner no less efficient than previously; “apparatus” means— electric lines or electrical plant as defined in the 1989 Act, belonging to or maintained by National Grid Electricity Transmission Plc together with any replacement apparatus; and such other apparatus constructed pursuant to the Order that becomes operational apparatus of the National Grid Electricity Transmission plc for the purposes of transmission, distribution and/or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus; “authorised works” has the same meaning as is given to the term “authorised development” in article 2(1) of this Order and for the purposes of this Part of this Schedule includes the use and maintenance of the authorised works and construction of any works authorised by this Schedule; “commence” and “commencement” in this Part of this Schedule will include any below ground surveys, monitoring, groundwork operations or the receipt and erection of construction plant and equipment; “deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, enactments and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule; “functions” includes powers and duties; “ground mitigation scheme” means a scheme approved by National Grid Electricity Transmission Plc (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event; “ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, will require the undertaker to submit for National Grid Electricity Transmission Plc’s approval a ground mitigation scheme; “ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme; “in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land; “Incentive Deduction” means any incentive deduction National Grid Electricity Transmission Plc Electricity Transmission plc receives under its electricity transmission licence which is caused by an event on its transmission system that causes electricity not to be supplied to a demand customer and which arises as a result of the authorised works; “maintain” and “maintenance” shall include the ability and right to do any of the following in relation to any apparatus or alternative apparatus of National Grid Electricity Transmission Plc: construct, use, repair, alter, inspect, renew or remove the apparatus; “National Grid Electricity Transmission Plc” means National Grid Electricity Transmission Plc (Company Number 2366977) whose registered office is at 1-3 Strand, London, WC2N 5EH or any successor as a licence holder within the meaning of Part 1 of the Electricity Act 1989; “NGESO” means as defined in the STC; “plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed; “parent company” means a parent company of the undertaker acceptable to and which will have been approved by National Grid Electricity Transmission Plc acting reasonably; “Peartree Hill Project works” means any part of Work Nos. 5, 6 or 8 described in Schedule 1 of this Order (authorised development); “specified works” means any of the authorised works or activities undertaken in association with the authorised works which— will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph 61(2) or otherwise; and/or may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under paragraph 61(2) or otherwise; and/or includes any of the activities that are referred to in development near overhead lines EN43-8 and HSE’s guidance note 6 “Avoidance of Danger from Overhead Lines”. “STC” means the System Operator Transmission Owner Code prepared by the electricity Transmission Owners and NGESO as modified from time to time; “STC Claims” means any claim made under the STC against National Grid Electricity Transmission Plc arising out of or in connection with the de-energisation (whereby no electricity can flow to or from the relevant system through the generator or interconnector’s equipment) of a generator or interconnector party solely as a result of the de-energisation of plant and apparatus forming part of National Grid Electricity Transmission Plc’s transmission system which arises as a result of the authorised works; “Transmission Owner” means as defined in the STC; “Wanlass Beck Project” means the proposed new substation to be known as the Wanlass Beck Substation, construction of access road from the A1079, diversion of Park Lane, overhead line works, utilities and watercourse crossings and associated works to be undertaken by National Grid Electricity Transmission Plc and any temporary construction compounds and laydown areas for such works; and “Wanlass Beck Site” includes— land on which any Wanlass Beck apparatus is situated; and land on which Wanlass Beck apparatus is anticipated to be situated which is necessary for the construction, use or maintenance of the Wanlass Beck Project (in so far as the same has been notified by National Grid Electricity Transmission Plc in writing to the undertaker). Interaction with the Wanlass Beck Project 56 Without limiting any other provision of this Part of this Schedule, the undertaker must use reasonable endeavours to avoid any conflict arising between the construction, maintenance and operation of the authorised works and the Wanlass Beck Project. For the purposes of this paragraph, “reasonable endeavours” means— (a) undertaking consultation on the detailed design and programming of the Peartree Hill project works and all works associated with or ancillary to the Peartree Hill project works to ensure that the design and programme for the Peartree Hill Project works does not unreasonably impede or interfere with the Wanlass Beck Project; (b) having regard to the proposed programme of works for the Wanlass Beck Project as may be made available to the undertaker by National Grid Electricity Transmission Plc and facilitating a co-ordinated approach to the programme, land assembly, and the carrying out of the Peartree Hill Project works and the Wanlass Beck Project; (c) providing a point of contact for continuing liaison and co-ordination throughout the construction and operation of the authorised works; and (d) keeping National Grid Electricity Transmission Plc informed on the programme of works for the authorised works. Peartree Hill Project works 57 (1) The undertaker must not construct any Peartree Hill Project works, or any part of it, without consulting National Grid Electricity Transmission Plc on the proposed plans of the relevant Peartree Hill Project works (or part of it) and considering their representations. (2) National Grid Electricity Transmission Plc must employ reasonable endeavours to respond to the submission of any plans within a period of 56 days from the date of submission of the plans. If National Grid Electricity Transmission Plc require further particulars, such particulars must be requested by National Grid Electricity Transmission Plc no later than 21 days from the submission of plans and thereafter National Grid Electricity Transmission Plc must employ reasonable endeavours to respond to the submission within 56 days from receipt of the further particulars. (3) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case, it must give to National Grid Electricity Transmission Plc notice as soon as is reasonably practicable and a plan of those works. (4) The undertaker must give to National Grid Electricity Transmission Plc not less than 14 days’ notice in writing of its intention to commence construction of any Peartree Hill Project works and provide a copy of the final plans for the Peartree Hill Project works and National Grid Electricity Transmission Plc will be entitled by its officer to watch and inspect the construction of such works. (5) The undertaker must give to National Grid Electricity Transmission Plc notice in writing of its completion of any Peartree Hill Project works not later than 7 days after the date on which it is completed (6) If any part of the Peartree Hill Project works is constructed otherwise than in accordance with the final plans provided under sub-paragraph 4(1) above National Grid Electricity Transmission Plc may by notice in writing identify the extent to which the Peartree Hill project works do not comply with the final plans provided and request the undertaker at the undertaker’s own expense carry out remedial works so as to comply with the final plans provided or such alternative works as may be agreed with National Grid Electricity Transmission Plc or as otherwise may be agreed between the parties. (7) Subject to sub-paragraph (8), if within a reasonable period, being not less than 28 days beginning with the date when a notice under sub-paragraph (6) is served upon the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, National Grid Electricity Transmission Plc may execute the works specified in the notice and any reasonable expenditure incurred by National Grid Electricity Transmission Plc in so doing will be recoverable from the undertaker. (8) In the event of any dispute as to whether sub-paragraph (6) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, National Grid Electricity Transmission Plc will not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (7) until the dispute has been finally determined in accordance with paragraph 70 (arbitration). On Street Apparatus 58 Except for paragraphs 59 (apparatus of National Grid Electricity Transmission Plc in temporarily closed or restricted streets), 64 (retained apparatus: protection of National Grid Electricity Transmission Plc as Electricity undertaker), 65 (expenses) and 66 (indemnity) of this Part of this Schedule which will apply in respect of the exercise of all or any powers under the Order affecting the rights and apparatus of National Grid Electricity Transmission Plc, the other provisions of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and National Grid Electricity Transmission Plc are regulated by the provisions of Part 3 of the 1991 Act. Apparatus of National Grid Electricity Transmission Plc in temporarily closed or restricted streets 59 Where any street is temporarily closed or restricted under the powers of article 15 (temporary closure or restriction of streets and public rights of way), National Grid Electricity Transmission Plc is at liberty at all times to take all necessary access across any such temporarily closed or restricted street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that street. Protective works to buildings 60 The undertaker, in the case of the powers conferred by article 20 (protective work to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus or the Wanlass Beck Site without the prior written consent of National Grid Electricity Transmission Plc which must not be unreasonably withheld. Acquisition of land 61 (1) Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference to the Order, the undertaker may not (a) appropriate or acquire or take temporary possession of any land or apparatus or (b) appropriate, acquire, extinguish, interfere with or override any easement, other interest or right and/or apparatus of National Grid Electricity Transmission Plc otherwise than by agreement. (2) Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not unless otherwise agreed in writing with National Grid Electricity Transmission Plc appropriate, acquire or take temporary possession of any land forming part of the Wanlass Beck Site, (such agreement not to be unreasonably withheld or delayed) and/or any access thereto. (3) As a condition of an agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised works (or in such other timeframe as may be agreed between National Grid Electricity Transmission Plc and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of National Grid Electricity Transmission Plc or affect the provisions of any enactment or agreement regulating the relations between National Grid Electricity Transmission Plc and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as National Grid Electricity Transmission Plc reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between National Grid Electricity Transmission Plc and the undertaker acting reasonably and which must be no less favourable on the whole to National Grid Electricity Transmission Plc unless otherwise agreed by National Grid Electricity Transmission Plc, and it will be the responsibility of the undertaker to procure and/or secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works. (4) Save where otherwise agreed in writing between National Grid Electricity Transmission Plc and the undertaker the undertaker and National Grid Electricity Transmission Plc agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation and/or removal of apparatus (including but not limited to the payment of costs and expenses relating to such relocation and/or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by National Grid Electricity Transmission Plc and/or other enactments relied upon by National Grid Electricity Transmission Plc as of right or other use in relation to the apparatus, then the provisions in this Schedule shall prevail. (5) Any agreement or consent granted by National Grid Electricity Transmission Plc under paragraph 64 (retained apparatus: protection of National Grid Electricity Transmission Plc as Electricity undertaker) or any other paragraph of this Part of this Schedule, shall not be taken to constitute agreement under sub-paragraph (1). Removal of apparatus 62 (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in or possesses temporarily any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of National Grid Electricity Transmission Plc to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of National Grid Electricity Transmission Plc in accordance with sub-paragraph (2) to (5). (2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to National Grid Electricity Transmission Plc a minimum of 56 days’ advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order National Grid Electricity Transmission Plc reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), secure any necessary consents for the alternative apparatus and afford to National Grid Electricity Transmission Plc to its satisfaction (taking into account paragraph 63(1) below) the necessary facilities and rights— (a) for the construction of alternative apparatus in other land of or land secured by the undertaker; and (b) subsequently for the maintenance of that apparatus. (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, National Grid Electricity Transmission Plc may in its sole discretion, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances to assist the undertaker to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation must not extend to the requirement for National Grid Electricity Transmission Plc to use its compulsory purchase powers to this end unless it elects to so do. (4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between National Grid Electricity Transmission Plc and the undertaker. (5) National Grid Electricity Transmission Plc must, after the alternative apparatus to be provided or constructed has been agreed, and subject to any necessary legal agreements having been entered between the parties and the grant to National Grid Electricity Transmission Plc of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule. Facilities and rights for alternative apparatus 63 (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for National Grid Electricity Transmission Plc facilities and rights in land for the construction, use, maintenance and protection of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and National Grid Electricity Transmission Plc and must be no less favourable on the whole to National Grid Electricity Transmission Plc than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by National Grid Electricity Transmission Plc. (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to National Grid Electricity Transmission Plc than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject the matter may be referred to arbitration in accordance with paragraph 70 (Arbitration) of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to National Grid Electricity Transmission Plc as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. Retained apparatus: protection of National Grid Electricity Transmission Plc as Electricity Undertaker 64 (1) Not less than 56 days before the commencement of any specified works the undertaker must submit to National Grid Electricity Transmission Plc a plan of the works to be executed and seek from National Grid Electricity Transmission Plc details of the underground extent of their electricity assets. (2) In relation to specified works the plan to be submitted to National Grid Electricity Transmission Plc under sub-paragraph (1) must include a method statement and describe— (a) the exact position of the works; (b) the level at which these are proposed to be constructed or renewed; (c) the manner of their construction or renewal including details of excavation, positioning of plant; (d) the position of all apparatus; (e) by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus; (f) any intended maintenance regimes; (g) an assessment of risks of rise of earth issues; and (h) a ground monitoring scheme, where required. (3) In relation to any works which will or may be situated on, over, under or within 10 metres of any part of the foundations of an electricity tower or between any two or more electricity towers, the plan to be submitted under sub-paragraph (1) must, in addition to the matters set out in sub-paragraph (2), include a method statement describing— (a) details of any cable trench design including route, dimensions, clearance to pylon foundations; (b) demonstration that pylon foundations will not be affected prior to, during and post construction; (c) details of load bearing capacities of trenches; (d) details of any cable installation methodology including access arrangements, jointing bays and backfill methodology; (e) a written management plan for high voltage hazard during construction and ongoing maintenance of any cable route; (f) written details of the operations and maintenance regime for any cable, including frequency and method of access; (g) assessment of earth rise potential if reasonably required by National Grid Electricity Transmission Plc’s engineers; and (h) evidence that trench bearing capacity is to be designed to support overhead line construction traffic of up to and including 26 tonnes in weight. (4) The undertaker must not commence any works to which sub-paragraphs (2) or (3) apply until National Grid Electricity Transmission Plc has given written approval of the plan so submitted. (5) Any approval of National Grid Electricity Transmission Plc required under sub-paragraphs (4)— (a) may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs (6) or (8); and, (b) may be given subject to such reasonable requirements as National Grid Electricity Transmission Plc may have in connection with the safe and efficient construction, commissioning, operation and maintenance of the Wanlass Beck Project and (c) must not be unreasonably withheld. (6) In relation to any work to which sub-paragraphs (2) or (3) apply, National Grid Electricity Transmission Plc may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage, for the provision of protective works or for the purpose of providing or securing proper and convenient means of access to any apparatus. (7) Works executed under sub-paragraphs (2) or (3) must be executed in accordance with the plan, submitted under sub-paragraph (1) or as relevant sub-paragraph (6), as approved under sub-paragraph (4) or as amended from time to time by agreement between the undertaker and National Grid Electricity Transmission Plc and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (5), (6), (8) or (9) by National Grid Electricity Transmission Plc for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid Electricity Transmission Plc will be entitled to watch and inspect the execution of those works. (8) Where National Grid Electricity Transmission Plc requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, such protective works must be carried out to National Grid Electricity Transmission Plc’s satisfaction prior to the commencement of any authorised works (or any relevant part thereof) for which protective works are required and National Grid Electricity Transmission Plc must give notice of its requirement for such works within 42 days of the date of submission of a plan pursuant to this paragraph (except in an emergency). (9) If National Grid Electricity Transmission Plc in accordance with sub-paragraphs (6) or (8) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, sub-paragraphs 1 to 3 and 6 to 8 apply as if the removal of the apparatus had been required by the undertaker under paragraph 62(2) (removal of apparatus). (10) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the authorised works, a new plan, instead of the plan previously submitted under paragraph (1), and having done so the provisions of this paragraph shall apply to and in respect of the new plan. (11) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to National Grid Electricity Transmission Plc notice as soon as is reasonably practicable a plan of those works and must comply with sub-paragraphs (6), (7) and (8) insofar as is reasonably practicable in the circumstances and comply with sub-paragraph (12) at all times. (12) At all times when carrying out any works authorised under the Order, the undertaker must comply with National Grid Electricity Transmission Plc’s policies for development near overhead lines EN43-8 and HSE’s guidance note 6 “Avoidance of Danger from Overhead Lines”. Expenses 65 (1) Save where otherwise agreed in writing between National Grid Electricity Transmission Plc and the undertaker and subject to the following provisions of this paragraph, the undertaker must pay to National Grid Electricity Transmission Plc within 30 days of receipt of an itemised invoice or claim from National Grid Electricity Transmission Plc all charges, costs and expenses reasonably anticipated within the following three months or reasonably and properly incurred by National Grid Electricity Transmission Plc in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised works including without limitation— (a) any costs reasonably incurred by or compensation properly paid by National Grid Electricity Transmission Plc in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs incurred by National Grid Electricity Transmission Plc as a consequence of National Grid Electricity Transmission Plc— (i) using its own compulsory purchase powers to acquire any necessary rights under paragraph 62(3) (removal of apparatus); or (ii) exercising any compulsory purchase powers in the Order transferred to or benefitting National Grid Electricity Transmission Plc; (b) in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus, where no written diversion agreement is otherwise in place; (c) the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus; (d) the approval of plans; (e) the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works; (f) the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule. (2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal. (3) If in accordance with the provisions of this Part of this Schedule— (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 70 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Grid Electricity Transmission Plc by virtue of sub-paragraph (1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker. (4) For the purposes of sub-paragraph (3)— (a) an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and (b) where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined. (5) Any amount which apart from this sub-paragraph would be payable to National Grid Electricity Transmission Plc in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Grid Electricity Transmission Plc any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit. Indemnity 66 (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Part of this Schedule or in consequence of the construction, use maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised works) or property of National Grid Electricity Transmission Plc, or there is any interruption in any service provided, or in the supply of any goods, by National Grid Electricity Transmission Plc, or National Grid Electricity Transmission Plc becomes liable to pay any amount to any third party, the undertaker will— (a) bear and pay on demand accompanied by an invoice or claim from National Grid Electricity Transmission Plc the cost reasonably and properly incurred by National Grid Electricity Transmission Plc in making good such damage or restoring the supply; and (b) indemnify National Grid Electricity Transmission Plc for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from National Grid Electricity Transmission Plc, by reason or in consequence of any such damage or interruption or National Grid Electricity Transmission Plc becoming liable to any third party and including STC Claims or an Incentive Deduction other than arising from any default of National Grid Electricity Transmission Plc. (2) The fact that any act or thing may have been done by National Grid Electricity Transmission Plc on behalf of the undertaker or in accordance with a plan approved by National Grid Electricity Transmission Plc or in accordance with any requirement of National Grid Electricity Transmission Plc or under its supervision will not (unless sub-paragraph (3) applies), excuse the undertaker from liability under the provisions of this sub-paragraph (1) unless National Grid Electricity Transmission Plc fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan. (3) Nothing in sub-paragraph (1) will impose any liability on the undertaker in respect of— (a) any damage or interruption to the extent that it is attributable to the neglect or default of National Grid Electricity Transmission Plc, its officers, servants, contractors or agents; (b) any authorised works and/or any other works authorised by this Part of this Schedule carried out by National Grid Electricity Transmission Plc as an assignee, transferee or lessee of the undertaker with the benefit of the Order pursuant to section 156 of the Planning Act 2008 or article 8 (consent to transfer benefit of Order) subject to the proviso that once such works become apparatus (“new apparatus”), any authorised works yet to be executed and not falling within this sub-paragraph (3)(b) will be subject to the full terms of this Part of this Schedule including this paragraph in respect of such apparatus; and/ or (c) any indirect or consequential loss of any third party (including but not limited to loss of use, revenue, profit, contract, production, increased cost of working or business interruption) arising from any such damage or interruption, which is not reasonably foreseeable. (4) National Grid Electricity Transmission Plc must give the undertaker reasonable written notice of any such third-party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations. (5) National Grid Electricity Transmission Plc must use all reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within National Grid Electricity Transmission Plc’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of National Grid Electricity Transmission Plc’s control and if reasonably requested to do so by the undertaker, National Grid Electricity Transmission Plc must provide an explanation of how the claim has been minimised, where relevant. (6) National Grid Electricity Transmission Plc must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds. (7) Not to commence construction (and not to permit the commencement of such construction) of the authorised works on any land owned by National Grid Electricity Transmission Plc or in respect of which National Grid Electricity Transmission Plc has an easement or wayleave for its apparatus or any other interest or to carry out any works within 15 metres of National Grid Electricity Transmission Plc’s apparatus until the following conditions are satisfied— (a) unless and until National Grid Electricity Transmission Plc is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has first provided the acceptable security (and provided evidence that it shall maintain such acceptable security for the construction period of the authorised works from the proposed date of commencement of construction of the authorised works) and National Grid Electricity Transmission Plc has confirmed the same to the undertaker in writing; and (b) unless and until National Grid Electricity Transmission Plc is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has procured acceptable insurance (and provided evidence to National Grid Electricity Transmission Plc that it shall maintain such acceptable insurance for the construction period of the authorised works from the proposed date of commencement of construction of the authorised works) and National Grid Electricity Transmission Plc has confirmed the same in writing to the undertaker. (8) In the event that the undertaker fails to comply with sub-paragraph (11)(7) of this Part of this Schedule, nothing in this Part of this Schedule shall prevent National Grid Electricity Transmission Plc from seeking injunctive relief (or any other equitable remedy) in any court of competent jurisdiction. Enactments and agreements 67 Save to the extent provided for to the contrary elsewhere in this Part of this Schedule or by agreement in writing between National Grid Electricity Transmission Plc and the undertaker, nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and National Grid Electricity Transmission Plc in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made. Co-operation 68 (1) Where in consequence of the proposed construction of any part of the authorised works, the undertaker or National Grid Electricity Transmission Plc requires the removal of apparatus under paragraph 62(2) (removal of apparatus) or National Grid Electricity Transmission Plc makes requirements for the protection or alteration of apparatus under paragraph 64 (retained apparatus: protection of National Grid Electricity Transmission Plc as Electricity undertaker), the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised works and taking into account the need to ensure the safe and efficient operation of National Grid Electricity Transmission Plc’s undertaking and National Grid Electricity Transmission Plc must use its best endeavours to co-operate with the undertaker for that purpose. (2) Whenever National Grid Electricity Transmission Plc’s consent, agreement or approval is required in relation to plans, documents or other information submitted by the undertaker or the taking of action by the undertaker, it must not be unreasonably withheld or delayed. Access 69 If in consequence of the agreement reached in accordance with paragraphs 61(1) and 62(2) (Acquisition of Land) or the powers granted under this Order the access to any apparatus and/or the Wanlass Beck Site is materially obstructed, the undertaker must provide such alternative means of access to such apparatus and/or the Wanlass Beck Site as will enable National Grid Electricity Transmission Plc to access, maintain or use the apparatus and/or the Wanlass Beck Site no less effectively than was possible before such obstruction. Arbitration 70 Save for differences or disputes arising under paragraph 62(2), 62(4) 63(1) and 64 any difference or dispute arising between the undertaker and National Grid Electricity Transmission Plc under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and National Grid Electricity Transmission Plc, be determined by arbitration in accordance with article 48 (arbitration). Notices 71 Any plans submitted to National Grid Electricity Transmission Plc by the undertaker pursuant to this Part must be submitted using the LSBUD system (https://lsbud.co.uk/) or to such other address as National Grid Electricity Transmission Plc may from time to time appoint instead for that purpose and notify to the undertaker in writing. PART 7 FOR THE PROTECTION OF RAILWAY INTERESTS Application 72 The provisions of this Part of this Schedule have effect, unless otherwise agreed in writing between the undertaker and Network Rail and, in the case of paragraph 88 (transfer of property, land and rights) of this Part of this Schedule any other person on whom rights or obligations are conferred by that paragraph. Interpretation 73 In this part of this Schedule— “asset protection agreement” means an asset protection agreement or basic asset protection agreement, as the case may be, in Network Rail’s standard form (as the same is amended from time to time) but amended to reflect the particular circumstances relating to works under the authorised development; “construction” includes execution, placing, alteration and reconstruction and “construct” and “constructed” have corresponding meanings; “the engineer” means an engineer appointed by Network Rail for the purposes of this Order; “network licence” means the network licence, as the same is amended from time to time, granted to Network Rail Infrastructure Limited by the Secretary of State in exercise of their powers under section 8 (licences) of the Railways Act 1993; “Network Rail” means Network Rail Infrastructure Limited (company number 02904587, whose registered office is at Waterloo General Office, London SE1 8SW) and any associated company of Network Rail Infrastructure Limited which holds property for railway purposes, and for the purpose of this definition “associated company” means any company which is (within the meaning of section 1159 of the Companies Act 2006) the holding company of Network Rail Infrastructure Limited, a subsidiary of Network Rail Infrastructure Limited or another subsidiary of the holding company of Network Rail Infrastructure Limited and any successor to Network Rail Infrastructure Limited’s railway undertaking; “plans” includes sections, designs, design data, software, drawings, specifications, soil reports, calculations, descriptions (including descriptions of methods of construction), staging proposals, programmes and details of the extent, timing and duration of any proposed occupation of railway property; “railway operational procedures” means procedures specified under any access agreement (as defined in the Railways Act 1993) or station lease; “railway property” means any railway belonging to Network Rail and— any station, land, works, apparatus and equipment belonging to Network Rail or connected with any such railway; and any easement or other property interest held or used by Network Rail or a tenant or licensee of Network Rail for the purposes of such railway or works, apparatus or equipment (evidence of which shall be provided by Network Rail to the undertaker as soon as reasonably practicable upon Network Rail’s receipt of written request from the undertaker); “regulatory consents” means any consent or approval required under— the Railways Act 1993; the network licence; and/or any other relevant statutory or regulatory provisions, by either the Office of Rail and Road or the Secretary of State for Transport or any other competent body including change procedures and any other consents, approvals or any access or beneficiary that may be required in relation to the authorised development. “specified work” means so much of any of the authorised development as is situated upon, across, under, over or within 15 metres of, or may in any way adversely affect, railway property. Railway operational procedures 74 (1) Where under this Part of this Schedule Network Rail is required to give its consent, agreement or approval in respect of any matter, that consent, agreement or approval is subject to the condition that Network Rail complies with any relevant railway operational procedures and any obligations under its network licence or under statute. (2) In so far as any specified work or the acquisition or use of railway property is or may be subject to railway operational procedures, Network Rail must— (a) co-operate with the undertaker with a view to avoiding undue delay and securing conformity as between any plans approved by the engineer and requirements emanating from those procedures; and (b) use their reasonable endeavours to avoid any conflict arising between the application of those procedures and the proper implementation of the authorised development pursuant to this Order. (3) The undertaker must not exercise the powers conferred by— (a) article 3 (Development consent etc. granted by this Order); (b) article 5 (Maintenance of authorised development); (c) article 18 (Discharge of water); (d) article 20 (Authority to survey and investigate the land); (e) article 21 (Compulsory acquisition of land); (f) article 24 (Compulsory acquisition of rights and imposition of restrictive covenants); (g) article 25 (Private rights over land); (h) article 26 (Power to override easements and other rights); (i) article 28 (Acquisition of subsoil only); (j) article 31 (Temporary use of land for carrying out the authorised development); (k) article 32 (Temporary use of land for maintaining the authorised development); (l) article 33 (Statutory undertakers); (m) article 40 (Felling or lopping of trees and removal of hedgerows); (n) article 41 (Trees subject to tree preservation orders); (o) the powers conferred by section 11(3) (power of entry) of the 1965 Act; (p) the powers conferred by section 203 (power to override easements and rights) of the Housing and Planning Act 2016; (q) the powers conferred by section 172 (right to enter and survey land) of the Housing and Planning Act 2016; or (r) any powers in respect of the temporary possession of land under the Neighbourhood Planning Act 2017, in respect of any railway property unless the exercise of such powers is with the consent of Network Rail. (4) The undertaker must not in the exercise of the powers conferred by this Order prevent pedestrian or vehicular access to any railway property, unless preventing such access is with the consent of Network Rail. (5) The undertaker must not exercise the powers conferred by sections 271 or 272 of the 1990 Act, article 33 (Statutory undertakers), article 26 (Power to override easements and other rights) or article 25 (Private rights over land), in relation to any right of access of Network Rail to railway property, but such right of access may be diverted with the consent of Network Rail. (6) The undertaker must not under the powers of this Order acquire or use or acquire new rights over, or seek to impose any restrictive covenants over, any railway property, or extinguish any existing rights of Network Rail in respect of any third party property, except with the consent of Network Rail. (7) The undertaker must not under the powers of this Order do anything which would result in railway property being incapable of being used or maintained or which would affect the safe running of trains on the railway. (8) Where Network Rail is asked to give its consent pursuant to this paragraph, such consent must not be unreasonably withheld but may be given subject to reasonable conditions but it shall never be unreasonable to withhold consent for reasons of operational or railway safety (such matters to be in Network Rail’s absolute discretion). (9) The undertaker must enter into an asset protection agreement prior to the carrying out of any specified work. Submission and approval of plans 75 (1) The undertaker must before commencing construction of any specified work supply to Network Rail proper and sufficient plans of that work for the reasonable approval of the engineer and the specified work must not be commenced except in accordance with such plans as have been approved in writing by the engineer or settled by arbitration under article 44 (arbitration). (2) The approval of the engineer under sub-paragraph (1) must not be unreasonably withheld or delayed, and if by the end of the period of 28 days beginning with the date on which such plans have been supplied to Network Rail the engineer has not intimated disapproval of those plans and the grounds of such disapproval the undertaker may serve upon the engineer written notice requiring the engineer to intimate approval or disapproval within a further period of 28 days beginning with the date upon which the engineer receives written notice from the undertaker. If by the expiry of the further 28 days the engineer has not intimated approval or disapproval, the engineer is deemed to have approved the plans as submitted. (3) If by the end of the period of 28 days beginning with the date on which written notice was served upon the engineer under sub-paragraph (2), Network Rail gives notice to the undertaker that Network Rail desires itself to construct any part of a specified work which in the reasonable opinion of the engineer will or may affect the stability of railway property or the safe operation of traffic on the railways of Network Rail then, if the undertaker desires such part of the specified work to be constructed (together with any adjoining part of the specified work which the undertaker reasonably requires to be constructed with that work), Network Rail must construct it without unreasonable delay on behalf of and to the reasonable satisfaction of the undertaker in accordance with the plans approved or deemed to be approved or settled under this paragraph, and under the supervision (where appropriate and if given) of the undertaker. (4) When signifying their approval of the plans the engineer may specify any protective works (whether temporary or permanent) which in the engineer’s reasonable opinion should be carried out before the commencement of the construction of a specified work to ensure the safety or stability of railway property or the continuation of safe and efficient operation of the railways of Network Rail or the services of operators using the same (including any relocation de-commissioning and removal of works, apparatus and equipment necessitated by a specified work and the comfort and safety of passengers who may be affected by the specified works), and such protective works as may be reasonably necessary for those purposes must be constructed by Network Rail or by the undertaker, if Network Rail so desires, and such protective works must be carried out at the reasonable expense of the undertaker in either case without unreasonable delay and the undertaker must not commence the construction of the specified works until the engineer has notified the undertaker that the protective works have been completed to the engineer’s reasonable satisfaction. 76 (1) Any specified work and any protective works to be constructed by virtue of paragraph 75(4) must, when commenced, be constructed— (a) without unnecessary delay in accordance with the plans approved or deemed to have been approved or settled under paragraph 75(1); (b) under the supervision (where appropriate and if given) and to the reasonable satisfaction of the engineer; (c) in such manner as to cause as little damage as is possible to railway property; and (d) so far as is reasonably practicable, so as not to interfere with or obstruct the free, uninterrupted and safe use of any railway of Network Rail or the traffic thereon and the use by passengers of railway property. (2) If any damage to railway property or any such interference or obstruction is caused by the carrying out of, or in consequence of the construction of a specified work, the undertaker must, notwithstanding any such approval, make good such damage and must pay to Network Rail all reasonable expenses properly incurred to which Network Rail may be put and compensation for any loss which it may sustain by reason of any such damage, interference or obstruction. (3) Nothing in this Part of this Schedule imposes any liability on the undertaker with respect to any damage, costs, expenses or loss attributable to the negligence of Network Rail or its employees, servants, contractors or agents or any liability on Network Rail with respect of any damage, costs, expenses or loss attributable to the negligence of the undertaker or its servants, contractors or agents. 77 The undertaker must— (a) at all times afford reasonable facilities to the engineer for access to a specified work during its construction; and (b) supply the engineer with all such information as the engineer may reasonably require with regard to a specified work or the method of constructing it. Access 78 Network Rail must at all times afford reasonable facilities to the undertaker and its agents for access to any works carried out by Network Rail under this Part of this Schedule during their construction and must supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them. Alterations and additions 79 (1) If any permanent or temporary alterations or additions to railway property are reasonably necessary in consequence of the construction or completion of a specified work during a period of 36 months after the completion of that work in order to ensure the safety of railway property or the continued safe operation of the railway of Network Rail, such alterations and additions may be carried out by Network Rail and if Network Rail gives to the undertaker 56 days’ notice (or in the event of an emergency or safety critical issue such notice as is reasonable in the circumstances) of its intention to carry out such alterations or additions (which must be specified in the notice including an estimate of the reasonable cost of carrying out, and where applicable in maintaining, working and, when necessary, renewing, those alterations or additions), the undertaker must pay to Network Rail the reasonable and proper cost of those alterations or additions including, in respect of any such alterations and additions as are to be permanent, a capitalised sum representing the increase of the costs which may be expected to be reasonably and properly incurred by Network Rail in maintaining, working and, when necessary, renewing any such alterations or additions. (2) If during the construction of a specified work by the undertaker, Network Rail gives notice to the undertaker that Network Rail desires itself to construct that part of the specified work which in the reasonable opinion of the engineer is endangering the stability of railway property or the safe operation of traffic on the railways of Network Rail then, if the undertaker decides that part of the specified work is to be constructed, Network Rail must assume construction of that part of the specified work and the undertaker must, notwithstanding any such approval of a specified work under paragraph 75(3), pay to Network Rail all properly and reasonably incurred expenses to which Network Rail may be put and compensation for any direct loss which it may suffer by reason of the execution by Network Rail of that specified work provided that at all times Network Rail will be under an obligation to take reasonable steps to mitigate its loss. (3) The engineer must, in respect of the capitalised sums referred to in this paragraph and paragraph 80(a) provide such details of the formula by which those sums have been calculated as the undertaker may reasonably require. (4) If the cost of maintaining, working or renewing railway property is reduced in consequence of any such alterations or additions a capitalised sum representing such saving must be set off against any sum payable by the undertaker to Network Rail under this paragraph. Expenses 80 The undertaker must repay to Network Rail all reasonable fees, costs, charges and expenses reasonably and properly incurred by Network Rail— (a) in constructing any part of a specified work on behalf of the undertaker as provided by paragraph 75(3) or in constructing any protective works under the provisions of paragraph 75(4) including, in respect of any permanent protective works, a capitalised sum representing the cost of maintaining and renewing those works; (b) in respect of the reasonable approval by the engineer of plans submitted by the undertaker and the supervision by the engineer of the construction of a specified work; (c) in respect of the employment or procurement of the services of any inspectors, signallers, watch-persons and other persons whom it is reasonably necessary to appoint for inspecting, signalling, watching and lighting railway property and for preventing, so far as may be reasonably practicable, interference, obstruction, danger or accident arising from the construction or failure of a specified work; (d) in respect of any special traffic working resulting from any speed restrictions which may in the reasonable opinion of the engineer, require to be imposed by reason or in consequence of the construction or failure of a specified work or from the substitution or diversion of services which may be reasonably necessary for the same reason; and (e) in respect of any additional temporary lighting of railway property in the vicinity of the specified works, being lighting made reasonably necessary by reason or in consequence of the construction or failure of a specified work. Electromagnetic interference 81 (1) In this paragraph— “EMI” means, subject to sub-paragraph (2), electromagnetic interference with Network Rail apparatus generated by the operation of the authorised development where such interference is of a level which adversely affects the safe operation of Network Rail’s apparatus; and “Network Rail’s apparatus” means any lines, circuits, wires, apparatus or equipment (whether or not modified or installed as part of the authorised development) which are owned or used by Network Rail for the purpose of transmitting or receiving electrical energy or of radio, telegraphic, telephonic, electric, electronic or other like means of signalling or other communications. (2) This paragraph applies to EMI only to the extent that such EMI is not attributable to any change to Network Rail’s apparatus carried out after approval of plans under paragraph 75(1) for the relevant part of the authorised development giving rise to EMI (unless the undertaker has been given notice in writing before the approval of those plans of the intention to make such change). (3) Subject to sub-paragraph (5), the undertaker must in the design and construction of the authorised development take all measures necessary to prevent EMI and must establish with Network Rail (both parties acting reasonably) appropriate arrangements to verify their effectiveness. (4) In order to facilitate the undertaker’s compliance with sub-paragraph (3)— (a) the undertaker must consult with Network Rail as early as reasonably practicable to identify all Network Rail’s apparatus which may be at risk of EMI, and thereafter must continue to consult with Network Rail (both before and after formal submission of plans under paragraph 4(1)) in order to identify all potential causes of EMI and the measures required to eliminate them; (b) Network Rail must make available to the undertaker all information in the possession of Network Rail reasonably requested by the undertaker in respect of Network Rail’s apparatus identified pursuant to sub-paragraph (a); and (c) Network Rail must allow the undertaker reasonable facilities for the inspection of Network Rail’s apparatus identified pursuant to sub-paragraph (a). (5) In any case where it is established that EMI can only reasonably be prevented by modifications to Network Rail’s apparatus, Network Rail must not withhold its consent unreasonably to modifications of Network Rail’s apparatus, but the means of prevention and the method of their execution must be selected in the reasonable discretion of Network Rail, and in relation to such modifications, paragraph 75(1) has effect subject to the sub-paragraph. (6) Prior to the commencement of operation of the authorised development the undertaker shall test the use of the authorised development in a manner that shall first have been agreed with Network Rail and if, notwithstanding any measures adopted pursuant to sub-paragraph (3), the testing of the authorised development causes EMI then the undertaker must immediately upon receipt of notification by Network Rail of such EMI either in writing or communicated orally (such oral communication to be confirmed in writing as soon as reasonably practicable after it has been issued) forthwith cease to use (or procure the cessation of use of) the undertaker’s apparatus causing such EMI until all measures necessary have been taken to remedy such EMI by way of modification to the source of such EMI or (in the circumstances, and subject to the consent, specified in sub-paragraph (5)) to Network Rail’s apparatus. (7) In the event of EMI having occurred— (a) the undertaker must afford reasonable facilities to Network Rail for access to the undertaker’s apparatus in the investigation of such EMI; (b) Network Rail must afford reasonable facilities to the undertaker for access to Network Rail’s apparatus in the investigation of such EMI; (c) Network Rail must make available to the undertaker any additional material information in its possession reasonably requested by the undertaker in respect of Network Rail’s apparatus or such EMI; and (d) the undertaker shall not allow the use or operation of the authorised development in a manner that has caused or will cause EMI until measures have been taken in accordance with this paragraph to prevent EMI occurring. (8) Where Network Rail approves modifications to Network Rail’s apparatus pursuant to sub-paragraphs (5) or (6)— (a) Network Rail must allow the undertaker reasonable facilities for the inspection of the relevant part of Network Rail’s apparatus; and (b) any modifications to Network Rail’s apparatus approved pursuant to those sub-paragraphs must be carried out and completed by the undertaker in accordance with paragraph 76. (9) To the extent that it would not otherwise do so, the indemnity in paragraph 85(1) applies to the costs and expenses reasonably incurred or losses suffered by Network Rail through the implementation of the provisions of this paragraph (including costs incurred in connection with the consideration of proposals, approval of plans, supervision and inspection of works and facilitating access to Network Rail’s apparatus) or in consequence of any EMI to which sub-paragraph (6) applies. (10) For the purpose of paragraph 80(a) any modifications to Network Rail’s apparatus under this paragraph are deemed to be protective works referred to in that paragraph. Adverse impact on railway property 82 If at any time after the completion of a specified work, not being a work vested in Network Rail, Network Rail gives notice to the undertaker informing it that the state of maintenance of any part of the specified work appears to be such as adversely affects the operation of railway property, the undertaker must, on receipt of such notice, take such steps as may be reasonably necessary to put that specified work in such state of maintenance as not adversely to affect railway property. Signage 83 The undertaker must not provide any illumination or illuminated sign or signal on or in connection with a specified work in the vicinity of any railway belonging to Network Rail unless it has first consulted Network Rail and it must comply with Network Rail’s reasonable requirements for preventing confusion between such illumination or illuminated sign or signal and any railway signal or other light used for controlling, directing or securing the safety of traffic on the railway. 84 Any additional expenses which Network Rail may reasonably and properly incur in altering, reconstructing or maintaining railway property under any powers existing at the making of this Order by reason of the existence of a specified work must, provided that 56 days’ previous notice of the commencement of such alteration, reconstruction or maintenance has been given to the undertaker, be repaid by the undertaker to Network Rail. Indemnity 85 (1) The undertaker must pay to Network Rail all reasonable and properly incurred costs, charges, damages and expenses not otherwise provided for in this Part of this Schedule (subject to the remaining provisions of this part of this Schedule and to article 48 (no double recovery)) which may be occasioned to or reasonably incurred by Network Rail— (a) by reason of the construction, maintenance or operation of a specified work or the failure thereof; (b) by reason of any act or omission of the undertaker or of any person in its employ or of its contractors or others whilst engaged upon a specified work; (c) by reason of any act or omission of the undertaker or any person in its employ or of its contractors or others whilst accessing to or egressing from the authorised development; (d) in respect of any damage caused to or additional maintenance required to, railway property or any such interference or obstruction or delay to the operation of the railway as a result of access to or egress from the authorised development by the undertaker or any person in its employ or of its contractors or others; or (e) in respect of costs incurred by Network Rail in complying with any railway operational procedures or obtaining any regulatory consents which procedures are required to be followed or consents obtained to facilitate the carrying out or operation of the authorised development; and the undertaker must indemnify and keep indemnified Network Rail from and against all claims and demands arising out of or in connection with a specified work or any such failure, act or omission provided Network Rail will be under an obligation to take reasonable steps to mitigate its loss: and the fact that any act or thing may have been done by Network Rail on behalf of the undertaker or in accordance with plans approved by the engineer or in accordance with any requirement of the engineer or under the engineer’s supervision does not (if it was done without negligence on the part of Network Rail or of any person in its employ or of its contractors or agents) excuse the undertaker from any liability under the provisions of this sub-paragraph. (2) Network Rail must— (a) give the undertaker reasonable written notice of any such claims or demands as soon as reasonably practicable after Network Rail became aware of any such claims or demands; (b) not admit liability or make any settlement or compromise of any such a claim or demand without the prior consent of the undertaker; (c) take all such reasonable steps to mitigate any liabilities relating to such claims or demands; and (d) keep the undertaker informed where reasonably practicable to do so in relation to the progress of any such claims and demands and have due regard to the undertaker’s representations in relation to them. (3) The sums payable by the undertaker under sub-paragraph (1) must include if relevant a sum equivalent to the relevant costs. (4) Subject to the terms of any agreement between Network Rail and a train operator regarding the timing or method of payment of the relevant costs in respect of that train operator, Network Rail must promptly pay to each train operator the amount of any sums which Network Rail receives under sub-paragraph (3) which relates to the relevant costs of that train operator. (5) The obligation under sub-paragraph (3) to pay Network Rail the relevant costs shall, in the event of default, be enforceable directly by any train operator concerned to the extent that such sums would be payable to that operator pursuant to sub‑paragraph (4). (6) In this paragraph— “the relevant costs” means the costs, direct losses and expenses (including loss of revenue) reasonably and properly incurred by each train operator as a consequence of any specified work including but not limited to any restriction of the use of Network Rail’s railway network as a direct result of the construction, maintenance or failure of a specified work or any such act or omission as mentioned in sub-paragraph (1); and “train operator” means any person who is authorised to act as the operator of a train by a licence under section 8 of the Railways Act 1993. Estimated ongoing expenses 86 (1) Network Rail must, on receipt of a request from the undertaker, from time to time provide the undertaker free of charge with written estimates of the costs, charges, expenses and other liabilities for which the undertaker is or will become liable under this Part of this Schedule (including the amount of the relevant costs mentioned in paragraph 85) and with such information as may reasonably enable the undertaker to assess the reasonableness of any such estimate or claim made or to be made pursuant to this Part of this Schedule (including any claim relating to those relevant costs). (2) Network Rail must provide an itemised invoice to the undertaker of all charges, costs, fees damages and expenses which are claimed under this Part of this Schedule and any payment due to Network Rail under this Part of this Schedule must be made within 30 days of receipt of the itemised invoice. Assessment of expenses 87 In the assessment of any sums payable to Network Rail under this Part of this Schedule there must not be taken into account any increase in the sums claimed that is attributable to any action taken by or any agreement entered into by Network Rail if that action or agreement was not reasonably necessary and was taken or entered into with a view to obtaining the payment of those sums by the undertaker under this Part of this Schedule or increasing the sums so payable. Transfer of property, land and rights 88 The undertaker and Network Rail may, subject in the case of Network Rail to compliance with the terms of its network licence, enter into, and carry into effect, agreements for the transfer to the undertaker of— (a) any railway property shown on the works and land plans and described in the book of reference; (b) any lands, works or other property held in connection with any such railway property; and (c) any rights and obligations (whether or not statutory) of Network Rail relating to any railway property or any lands, works or other property referred to in this paragraph. Part I of the Railways Act 1993 89 Nothing in this Order, or in any enactment incorporated with or applied by this Order, prejudices or affects the operation of Part I of the Railways Act 1993. Application under article 7 (consent to transfer benefit of Order) 90 The undertaker must give written notice to Network Rail if any application is proposed to be made by the undertaker for the Secretary of State’s consent, under article 7 (consent to transfer benefit of Order) of this Order and any such notice must be given no later than 28 days before any such application is made and must describe or give (as appropriate)— (a) the nature of the application to be made; (b) the extent of the geographical area to which the application relates; and (c) the name and address of the person acting for the Secretary of State to whom the application is to be made. Certification of plans 91 The undertaker must no later than 28 days from the date that the plans submitted to and certified by the Secretary of State in accordance with article 42 (certification of plans etc.) are certified by the Secretary of State, provide a set of those plans to Network Rail in a format specified by Network Rail. Application of article 44 (arbitration) 92 Any difference under the provisions of this Part of the Schedule must be, unless otherwise agreed in writing between the undertaker and Network Rail, determined by arbitration in accordance with article 44 (arbitration). PART 8 FOR THE PROTECTION OF NORTHERN POWERGRID Application 93 For the protection of Northern Powergrid the following provisions have effect, unless otherwise agreed in writing between the undertaker and Northern Powergrid. 94 In this Part of this Schedule— “alternative apparatus” means alternative and / or replacement apparatus adequate to enable Northern Powergrid to fulfil its statutory functions in a manner not less efficient than previously; “apparatus” means electric lines or electrical plant (as defined in the Electricity Act 1989) belonging to or maintained by Northern Powergrid and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus; “authorised works” means so much of the works authorised by this Order which affect the operation or maintenance of or anything which is incidental to or ancillary to the operation and maintenance of existing Northern Powergrid’s apparatus within the Order limits; “functions” includes powers and duties; “in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; “plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed and shall include measures proposed by the undertaker to ensure the grant of sufficient land or rights in land necessary to mitigate the impacts of the works on Northern Powergrid’s undertaking; and “Northern Powergrid” means Northern Powergrid (Yorkshire) PLC (Company Number 04112320) whose registered address is Lloyds Court, 78 Grey Street, Newcastle upon Tyne NE1 6AF. Application of the 1991 Act 95 This Part of this Schedule does not apply to apparatus and / or alternative apparatus in respect of which the relations between the undertaker and Northern Powergrid are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act. Access to temporarily closed or restricted streets 96 Regardless of the temporary closure or restriction of streets under the powers conferred by article 14 of the Order (temporary closure or restriction of streets and public rights of way), Northern Powergrid is at liberty at all times to take all necessary access across any such temporarily closed or restricted street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street. Restriction on acquisition of apparatus and rights 97 Regardless of any provision in this Order or anything shown on the land plans, or contained in the book of reference, the undertaker shall not acquire any apparatus or override any easement or other interest of Northern Powergrid otherwise than by agreement with Northern Powergrid (such agreement not to be unreasonably withheld or delayed) and having regard to Norther Powergrid’s existing and known future requirements for such land or interests. Restriction on interference with communications equipment 98 Regardless of any provision in the Order or anything shown on the land plans or contained in the book of reference, the undertaker shall not interfere with any communications cables or equipment used by Northern Powergrid in relation to its apparatus nor shall acquire or interfere with rights or interests supporting the use, maintenance or renewal of such equipment including any easements other than by agreement of Northern Powergrid such agreement not to be unreasonably withheld . Removal of apparatus 99 (1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed in or over which access to any apparatus is enjoyed or requires that Northern Powergrid’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of Northern Powergrid to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided pursuant to a completed easement which shall include rights to retain and subsequently maintain the apparatus being replaced or diverted for the lifetime of that alterative apparatus, all to the reasonable satisfaction of Northern Powergrid in accordance with sub-paragraphs (2) to (5). (2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to Northern Powergrid 90 days’ advance written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order Northern Powergrid reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to Northern Powergrid the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus. (3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed— (a) the undertaker must in the first instance use reasonable endeavours to acquire all necessary land interests or rights as Northern Powergrid may reasonably require for the relocation and construction of alternative apparatus and must use reasonable endeavours to procure all necessary rights to access and maintain Northern Powergrid’s apparatus and alternative apparatus thereafter the terms of such access and maintenance to be agreed by Northern Powergrid (acting reasonably); (b) in the event that the undertaker is not able to procure the necessary land interest or rights referred to in the sub-paragraph (3)(a) Northern Powergrid must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably practicable and at the cost of the undertaker (subject to prior approval by the undertaker of its estimate of costs of doing so) use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation shall not extend to the requirement for Northern Powergrid to use its compulsory purchase powers to this end. (4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Northern Powergrid and the undertaker or in default of agreement settled by arbitration in accordance with article 44 (arbitration). (5) Northern Powergrid must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 44 (arbitration), and after the grant to Northern Powergrid of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule. Facilities and rights for alternative apparatus 100 (1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to Northern Powergrid facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and Northern Powergrid or in default of agreement settled by arbitration in accordance with article 44 (arbitration). (2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to Northern Powergrid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to Northern Powergrid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. Retained apparatus: protection of Northern Powergrid 101 (1) Not less than 90 days before starting the execution of any authorised works in, on or under any land purchased, held, appropriated or used under this Order (including conducting any activities whether intentionally or unintentionally, through for example ground or machinery collapse, which may affect Northern Powergrid’s apparatus or encroach on safety distances to live equipment) or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 99(2), the undertaker must submit to Northern Powergrid a plan, section and description of the works to be executed and any such information as Northern Powergrid reasonably required relating to those works. (2) Those authorised works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by Northern Powergrid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and Northern Powergrid is entitled to watch and inspect the execution of those works. (3) Any requirements made by Northern Powergrid under sub-paragraph (2) must be made within a period of 42 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it. (4) If Northern Powergrid in accordance with sub-paragraph (3) and in consequence of the authorised works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, sub-paragraphs 1 to 6 apply as if the removal of the apparatus had been required by the undertaker under paragraph (2). (5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 42 days before commencing the execution of any authorised works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description. (6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to Northern Powergrid notice as soon as is reasonably practicable and a plan, section and description of those authorised works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances. Expenses 102 (1) Subject to the following provisions of this paragraph, the undertaker must repay to Northern Powergrid within fifty (50) days of the date of the receipt of an itemised invoice or a claim for all reasonable and proper expenses, costs or charges reasonably and properly incurred by Northern Powergrid— (a) in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 99(2) including without limitation— (i) any costs reasonably incurred by or compensation properly paid by Northern Powergrid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation in the event that Northern Powergrid acquires any necessary land and / or rights for alternative apparatus by voluntary negotiation or elects to use its compulsory purchase powers to acquire any necessary rights under paragraph 99(3) all costs reasonably incurred as a result of such action; (ii) in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus; (iii) the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus; (iv) the approval of plans; (v) the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works; (vi) the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule); and (b) in assessing and preparing a design for its apparatus including alternative apparatus to address and accommodate the proposals of the undertaker whether or not the undertaker proceeds to implement those proposals or alternative or none at all, provided that if it so prefers Northern Powergrid may abandon apparatus that the undertaker does not seek to remove in accordance with paragraph 99(1) having first decommissioned such apparatus. (2) Where any payment falls due pursuant to sub-paragraph (1), Northern Powergrid shall— (a) provide an itemised invoice or reasonable expenses claim to the undertaker; (b) provide ‘reminder letters’ to the undertaker for payment to be made within the fifty days on the following days after the invoice or reasonable expenses claim to the undertaker— (i) 15 days (‘reminder letter 1’); (ii) 29 days (‘reminder letter 2’); (iii) 43 days (‘reminder letter 3’); and (c) be entitled to commence debt proceedings to recover any unpaid itemised invoice or reasonable expenses claim after fifty one (51) days of receipt of the same where payment has not been made. (3) There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal and for the avoidance of doubt, if the apparatus removed under the provisions of this Part of this Schedule has nil value, no sum will be deducted from the amount payable under sub-paragraph (1)if in accordance with the provisions of this Part of this Schedule— (a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or (b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated, (4) and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 44 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to Northern Powergrid by virtue of sub-paragraph (1) is to be reduced by the amount of that excess save where it is not in the circumstances possible on account of project time limits and/or supply interest to obtain the existing type of apparatus at the same capacity dimensions or place at the existing depth in which case full costs shall be borne by the undertaker. (5) For the purposes of sub-paragraph (3)— (a) an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 99(2); and (b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined. Indemnity 103 (1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the authorised works referred to in in paragraph 99(2), or in consequence of the, maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by it) in the course of carrying out such authorised works, including without limitation authorised works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Northern Powergrid, or there is any interruption in any service provided by Northern Powergrid, or Northern Powergrid becomes liable to pay any amount to a third party as a consequence of any default, negligence or omission by the undertaker in carrying out the authorised works, the undertaker must— (a) bear and pay the cost reasonably and properly incurred by Northern Powergrid in making good such damage or restoring the supply; and (b) indemnify Northern Powergrid for any other expenses, loss, damages, penalty, proceedings, claims or costs incurred by or recovered from Northern Powergrid by reason or in consequence of any such damage or interruption or Northern Powergrid becoming liable to any third party. (2) Nothing in sub-paragraph (1) imposes any liability on the undertaker in respect of any damage or interruption to the extent that it is attributable to the neglect or negligence of Northern Powergrid, its officers, employees, servants, contractors or agents. (3) Northern Powergrid must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand. (4) Northern Powergrid must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably as it would as if settling third party claims on its own behalf from its own funds. (5) Northern Powergrid must use its reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph 103 applies. If requested to do so by the undertaker, Northern Powergrid must provide an explanation of how the claim has been minimised or details to substantiate any cost or compensation claimed pursuant to sub-paragraph (1). The undertaker shall only be liable under this paragraph 103 for claims reasonably incurred by Northern Powergrid. (6) Subject to sub-paragraphs (4) and (5), the fact that any act or thing may have been done by Northern Powergrid on behalf of the undertaker or in accordance with a plan approved by Northern Powergrid or in accordance with any requirement of Northern Powergrid as a consequence of the authorised development or under its supervision will not (unless sub-paragraph (2) applies), excuse the undertaker from liability under the provisions of this sub-paragraph (6) where the undertaker fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan or as otherwise agreed between the undertaker and the Northern Powergrid. Enactments and agreements 104 Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and Northern Powergrid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made. Arbitration 105 Any difference under the provisions of this Part of the Schedule, unless otherwise agreed is to be referred to and settled by arbitration in accordance with article 44 (arbitration). Co-ordination and co-operation 106 Where in consequence of the proposed construction of any of the authorised works, the undertaker or Northern Powergrid requires the removal of apparatus under paragraph 99 or otherwise or Northern Powergrid makes requirements for the protection or alteration of apparatus under paragraph 101, the undertaker shall use its reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the need to ensure the safe and efficient operation of Northern Powergrid’s undertaking taking into account the undertaker’s desire for the efficient and economic execution of the authorised development and the undertaker and Northern Powergrid shall use reasonable endeavours to co-operate with each other for those purposes. Access 107 If in consequence of an agreement reached in accordance with paragraph 98 or the powers granted under this Order the access to any apparatus or alternative apparatus is materially obstructed, the undertaker shall provide such alternative means of access to such apparatus or alternative apparatus as will enable Northern Powergrid to maintain or use the said apparatus no less effectively than was possible before such obstruction. Plans 108 The plans submitted to Northern Powergrid by the undertaker pursuant to this Part of the Schedule must be sent to Northern Powergrid at property@northernpowergrid.com or such other address as Northern Powergrid may from time to time appoint instead for that purpose and notify to the undertaker in writing. Notices 109 Prior to carrying out any authorised works within the Order Limits (as defined in the Order) Northern Powergrid must give written notice of the proposed works to the undertaker, such notice to include full details of the location of the proposed works, their anticipated duration, access arrangements, depths of the works, and any other information that may impact upon the works consented by the Order. Co-operation 110 Where practicable, the undertaker and Northern Powergrid will make reasonable efforts to liaise and co-operate in respect of information that is relevant to the safe and efficient construction operation and maintenance of the authorised development. Such liaison shall be carried out where any authorised works are— (a) within 15m of any above ground apparatus; and/or (b) within 15m of any apparatus and are to a depth of between 0 – 4m below ground level under any apparatus.